UNITED STATES

SECURITIES AND EXCHANGE COMMISSION

Washington, D.C. 20549

Form 6–K

REPORT OF FOREIGN PRIVATE ISSUER

PURSUANT TO RULE 13a-16 OR 15d-16

UNDER THE SECURITIES EXCHANGE ACT OF 1934

For the Month of November 2026

Commission File Number 001-31583

NAM TAI PROPERTY INC.

(Registrant’s name)

Nam Tai Property Inc.

No. 2 Namtai Road, Gushu Community, Xixiang Township

Bao’an District, Shenzhen City, Guangdong Province

People’s Republic of China

(Address of principal executive office)

Indicate by check mark whether the registrant files or will file annual reports under cover Form 20-F or Form 40-F.

Form 20-F ☒ Form 40-F ☐

SIGNATURES

Pursuant to the requirements of the Securities Exchange Act of 1934, the registrant has duly caused this report to be signed on its behalf by the undersigned, thereunto duly authorized.

NAM TAI PROPERTY INC.

Reports Q3 2026 Results

Shenzhen, China – November 12, 2026 – Nam Tai Property Inc. (OTC Market Symbol: NTPIF) (collectively with its subsidiaries, “Nam Tai” or the “Company”) today announced its unaudited results for the third quarter ended September 30, 2026.

The following tables set forth key highlights of the financial information for the periods indicated:

(In thousands of US dollars, except per share data, percentages and as otherwise stated)

Notes:

SUPPLEMENTARY INFORMATION (UNAUDITED) IN THE THIRD QUARTER OF 2026

Key Highlights of Financial Position

Notes:

FINANCIAL RESULTS*

*Amounts presented as totals or differences in this “Financial Results” section may not precisely equal the sum or difference of the component amounts due to rounding.

Revenue

Revenue for the third quarter of 2026 was $5.1 million compared to $9.7 million in the third quarter of 2025. Revenue for the third quarter of 2026 mainly consisted of the sales of property income from Nam Tai • Longxi of $1.1 million, operating lease income of $2.0 million from Nam Tai Inno Park, operating lease income of $0.4 million from Nam Tai Inno Valley, and property service income of $0.9 million from Nam Tai Inno Park and Nam Tai Inno Valley, and other income of $0.7 million. Revenue for the third quarter of 2025 mainly consisted of the sales of property income from Nam Tai • Longxi of $5.6 million, operating lease income of $2.3 million from Nam Tai Inno Park, operating lease income of $0.3 million from Nam Tai Inno Valley, and property service income of $0.8 million from Nam Tai Inno Park and Nam Tai Inno Valley, and other income of $0.7 million. The decrease in revenue was primarily attributable to a substantial decrease in sales of property income at Nam Tai • Longxi, reflecting a lower volume of residential units delivered as the residential portion of the project entered its final sales stage, including the impact of freezing order imposed by the court on certain residential units in connection with the Nam Tai • Longxi general contractor dispute, as well as lower average selling prices amid challenging property market conditions.

One of our primary sources of revenue growth in the next 12 months is sales of property income and operating lease income from the Nam Tai Technology Center project, once it is completed and operational. However, we cannot assure you as to when the project will begin contributing to revenue or the extent of any such contributions. The timing and amount of any revenue from this project are subject to various factors including without limitation, the delivery schedule of Nam Tai Technology Center project, the timing of the sale and leasing of Nam Tai Technology Center project, and any adverse changes in residential and leasing market conditions. We expect revenue to remain under downward pressure in the fourth quarter of 2026, primarily reflecting the continued wind-down of residential deliveries at Nam Tai • Longxi as the project approaches its final stage, together with ongoing soft conditions in the broader property sales and leasing markets. Revenue contribution from the Nam Tai Technology Center is not expected until early 2027, subject to the completion of necessary regulatory procedures. Please refer to Part I, Item 3.D. “Risk Factors” in our Annual Report on Form 20-F for the year ended December 31, 2025 (“Annual Report on Form 20-F”) for factors affecting our revenue and results of operations.

Cost of Revenue

Cost of revenue for the third quarter of 2026 was $3.2 million compared to $6.7 million in the third quarter of 2025. Cost of revenue for the third quarter of 2026 mainly consisted of the sales of property cost from Nam Tai • Longxi of $0.9 million, operating lease cost of $1.1 million from Nam Tai Inno Park, operating lease cost of $0.1 million from Nam Tai Inno Valley, property service cost of $1.1 million from Nam Tai Inno Park and Nam Tai Inno Valley. Cost of revenue for the third quarter of 2025 mainly consisted of the sales of property cost from Nam Tai • Longxi of $4.2 million, operating lease cost of $1.1 million from Nam Tai Inno Park, operating lease cost of $0.1 million from Nam Tai Inno Valley, property service cost of $1.3 million from Nam Tai Inno Park and Nam Tai Inno Valley. We expect our sales of property cost to decrease in the fourth quarter of 2026 and to fluctuate for the foreseeable future in line with our sales of property income. As our operating lease cost consists primarily of fixed costs, we expect it to remain relatively stable for the foreseeable future.

Gross Profit

Gross profit for the third quarter of 2026 was $1.9 million compared to $2.9 million in the third quarter of 2025. The decrease in gross profit was primarily attributable to lower revenue as discussed above.

General and administrative expenses

General and administrative expenses for the third quarter of 2026 were $3.9 million, compared with $3.3 million in the third quarter of 2025. General and administrative expenses for the third quarter of 2026 mainly consisted of staff costs of $1.9 million, professional service fees of $0.9 million, PRC taxes and surcharges of $0.6 million and office expenses of $0.5 million. General and administrative expenses for the third quarter of 2025 mainly consisted of staff costs of $1.9 million, PRC taxes and surcharges of $0.7 million, office expenses of $0.5 million, and professional service fees of $0.2 million. The increase in general and administrative expenses of $0.6 million in the third quarter of 2026 was mainly due to the increase in professional service fees.

Selling and marketing expenses

Selling and marketing expenses for the third quarter of 2026 were $0.5 million, compared with $0.9 million in the third quarter of 2025. Selling and marketing expenses for the third quarter of 2026 mainly consisted of staff costs of $0.3 million and marketing and commission fees of $0.1 million. The corresponding expenses for the third quarter of 2025 mainly consisted of staff costs of $0.4 million, marketing and commission fees of $0.3 million, and property management fees of $0.1 million. The decrease was mainly due to lower sales bonuses and commission fees resulting from decreased sales at Nam Tai • Longxi. We expect our selling and marketing expenses to increase after we generate sales from Nam Tai Technology Center, once it is completed and operational.

Net Loss from Operations

Net loss from operations for the third quarter of 2026 was $2.6 million compared to net loss from operations of $1.3 million in the third quarter of 2025. The increase in operating loss was primarily attributable to a $1.1 million decrease in gross profit and a $0.6 million increase in general and administrative expenses, partially offset by a $0.3 million decrease in selling and marketing expenses.

Consolidated Net Loss (Income)

Consolidated net loss for the third quarter of 2026 was $3.0 million compared to consolidated net loss of $1.9 million in the third quarter of 2025. Consolidated net loss for the third quarter of 2026 mainly consisted of net loss from operations of $2.6 million, other net expenses of $1.2 million, partially offset by income tax benefits of $0.7 million. Consolidated net loss for the third quarter of 2025 mainly consisted of net loss from operations of $1.3 million and other net expenses of $1.1 million, partially offset by income tax benefits of $0.4 million.

Cash and Cash Equivalents

Cash and cash equivalents decreased by $24.6 million in the first nine months of 2026 from $43.5 million as of December 31, 2025 to $18.9 million as of September 30, 2026. The decrease was primarily attributable to net cash used in operating activities and financing activities, partially offset by net cash provided by investing activities and the positive effect of exchange rate changes.

Restricted Cash

Restricted cash increased by $1.5 million in the first nine months of 2026 from $10.1 million as of December 31, 2025 to $11.7 million as of September 30, 2026. As of September 30, 2026, restricted cash consisted of loan security deposit accounts and certificates of

deposit of $9.5 million, $1.4 million restricted in connection with the freezing orders issued by the relevant PRC courts, a security cash deposit of $0.7 million due to a guarantee to the bank for the repayment of the loans of our long-term rental customers, which will be gradually released as the loans are repaid, and $0.1 million frozen by other restrictions.

Real Estate Properties under Development, Net

Real estate properties under development, net increased by $26.8 million in the first nine months of 2026 from $220.7 million as of December 31, 2025 to $247.5 million as of September 30, 2026, primarily attributable to the increase for the construction of Nam Tai Technology Center.

Real estate properties held for sale

Real estate properties held for sale are stated at the lower of carrying amounts or fair value less selling costs. Real estate properties held for sale decreased by $6.6 million from $22.1 million as of December 31, 2025 to $15.5 million as of September 30, 2026. The decrease was mainly due to the handover of sold units at Nam Tai • Longxi during the first nine months of 2026.

Real estate properties held for lease, net

Real estate properties held for lease, net are recorded at cost less accumulated depreciation. Real estate properties held for lease, net increased by $2.3 million from $128.6 million as of December 31, 2025 to $130.9 million as of September 30, 2026, which was primarily attributable to the appreciation of the Renminbi against the US dollar during the first nine months of 2026.

Property, plant and equipment, net

Property, plant and equipment, net remained relatively stable at $7.2 million as of September 30, 2026, compared with $7.2 million as of December 31, 2025.

Accounts Payable

Accounts payable decreased by $1.1 million in the first nine months of 2026 from $31.6 million as of December 31, 2025 to $30.5 million as of September 30, 2026. The decrease was mainly attributable to the settlement of outstanding payables to suppliers and contractors during the period.

Advance from Customers

Advance from customers increased by $6.1 million in the first nine months of 2026 from $1.0 million as of December 31, 2025 to $7.1 million as of September 30, 2026. The increase was mainly attributable to advance rental payments of $2.2 million received from tenants at Nam Tai Inno Park, and customer deposits received under purchase intention agreements for units at Nam Tai Technology Center of $3.9 million.

Current Portion of Long Term Bank Loans

The current portion of long term bank loans increased by $4.2 million in the first nine months of 2026 from $3.9 million as of December 31, 2025 to $8.1 million as of September 30, 2026. The increase was mainly attributable to scheduled principal repayments on long term bank loans falling due within the next 12 months.

Liquidity and Capital Resources

As of September 30, 2026, the Company had total cash and cash equivalents of $18.9 million. As of December 31, 2025, the Company had total cash and cash equivalents of $43.5 million. The decrease was primarily attributable to net cash used in operating activities, mainly reflecting (i) lower cash receipts from property sales at Nam Tai • Longxi as the project approached its final sales stage, and (ii) increased payments to contractors for Nam Tai Technology Center as construction progressed toward completion, as well as net cash used in financing activities, primarily for the repayment of shareholder loans.

During the third quarter of 2026, the Company secured additional bank financing and made further drawdowns under existing loan facilities to support the construction of Nam Tai Technology Center and the Company’s working capital needs. The Company continues to pursue further financing opportunities and management believes that, upon completion, Nam Tai Technology Center is expected to generate new rental and sales revenue once the project opens. However, any penalty payment that the Company would likely be required to make in connection with its obligations under the land use rights grant contract for Nam Tai Technology Center, as described below, would reduce the financial resources available for the Company’s operations and development projects. The Company will continue to monitor its liquidity position closely and manage its working capital prudently, as it seeks to advance its key projects and strengthen its liquidity position.

BUSINESS OVERVIEW

Leasing and Sales Progress

As of September 30, 2026, we had a total leasable area of approximately 292,819 square meters located in Shenzhen. As of September 30, 2026, the occupancy rate of our projects (i.e., Nam Tai Inno Park and Nam Tai Inno Valley), including pre-leased areas, was approximately 73%. As of September 30, 2026, the occupancy rate of Nam Tai Inno Park was 72%, a decrease of 2 percentage points as compared with September 30, 2025; the occupancy rate of Nam Tai Inno Valley was 80%, an increase of 23 percentage points as compared with September 30, 2025.

In the third quarter of 2026, no residential units and 22 parking units of Nam Tai • Longxi were newly subscribed, compared with 57 residential units in the third quarter ended September 30, 2025.

Project Construction and Development Progress

Real Estate Market Update

RECENT DEVELOPMENTS

Update on RMB 740 Million Onshore Financing

In July 2026, the Company announced two onshore financing transactions totaling RMB 740 million: (i) a RMB 700 million, 15-year fixed asset loan facility from Ping An Bank Co., Ltd., Shenzhen Branch (“Ping An Bank”) for the Nam Tai Inno Park project, and (ii) a RMB 40 million, five-year non-revolving credit facility from Shenzhen Rural Commercial Bank Co., Ltd., Xixiang Branch (“Shenzhen Rural Commercial Bank”) for the Company’s Qianhai project.

With respect to the Ping An Bank facility, during the third quarter of 2026, the Company completed the refinancing of its existing loan with China CITIC Bank Corporation Limited by drawing down RMB 588 million under the new facility to fully repay the outstanding loan. The remaining RMB 112 million was drawn down in October 2026, for other permitted purposes under the facility.

With respect to the Shenzhen Rural Commercial Bank facility, as of September 30, 2026, RMB 30 million had been drawn down under this facility.

Nam Tai • Longxi General Contractor Dispute

In July 2025, the Company received a notice from Shenzhen Guangshengda Construction Co., Ltd. (“Guangshengda”) regarding the assignment of claims for Nam Tai • Longxi project under its general construction contract to Shenzhen Weiyueda Mechanical & Electrical Installation Engineering Co., Ltd. (“Weiyueda”). The Company responded in August 2025, disputing and refusing to acknowledge the validity of such assignment. The Company believes the assignment is invalid due to, among other reasons, Guangshengda’s failure to fully perform its post-warranty maintenance obligations, which has led to customer complaints and potential group disputes; the ongoing and unresolved final project settlement process, which includes potential claims for liquidated damages against Guangshengda for project delays; and Guangshengda’s failure to issue the full amount of required invoices for the project.

In late August 2025, 54 residential units of the project were frozen by a court order following a pre-litigation asset preservation application filed by Weiyueda.

In September 2025, the Company filed a jurisdictional challenge, arguing that the case should be heard by a court in Shenzhen. The Company has also applied to substitute the frozen assets, specifically the pre-sold properties, with other unencumbered assets. Both applications have not been approved.

In October 2025, Weiyueda’s legal counsel proposed a potential settlement involving the transfer of properties in lieu of cash payment. This proposal was reviewed by the Company but no agreement was reached.

In January 2026, the court held the first hearing, but no judgment was rendered. The court provided both parties with additional time to finalize settlement calculations. A second hearing was held in April 2026. Subsequently, the court approved a judicial appraisal of the construction work. The appraisal process is currently ongoing, and no judgment has been issued as of the date of this report. Separately, in May 2026, the court granted an objection filed by the purchasers of one of the frozen residential units, and the freezing order over that unit has accordingly been lifted.

This litigation remains pending before the court, and the timing and outcome remain uncertain. The freezing of properties has impeded their sale, which could adversely affect our project sales and cash flow if not resolved in a timely manner. As of the date of this report, no additional provision has been recorded in respect of this matter.

Nam Tai • Longxi Staged Mortgage Guarantees Dispute

As part of the Company’s ordinary course of business for sales of residential properties for the Nam Tai • Longxi project and consistent with industry practice, the Company provides temporary mortgage guarantees to purchasers until the purchasers receive their title certificates and mortgage their properties to relevant commercial banks. If a purchaser defaults on the payment of its mortgage during such interim period, the mortgage lending bank may require the Company to repay the outstanding amount under the mortgage loan plus any accrued interest.

In March 2026, the Company received two arbitration notices concerning staged mortgage guarantees of the Dongguan Longxi Project, with principal and accrued interest of approximately RMB 1.8 million and RMB 2.4 million, respectively, totaling approximately $0.6 million. The Company has submitted its evidence in response to the arbitration proceedings. Both cases are proceeding on a written-submission basis and are awaiting arbitral awards. As of the date of this report, no provision has been recorded in respect of these matters.

Shenzhen Anju Master Lease Arrangement

In December 2025, the Company entered into a six-year master lease agreement with Shenzhen Anju Leyu Development & Construction Co., Ltd. (“Shenzhen Anju”), a state-owned enterprise that manages the rental housing program for the Futian District Government, covering approximately 456 dormitory units across approximately 24,000 square meters of facilities at the Nam Tai Technology Center project in Bao’an District.

During the third quarter of 2026, the Company determined not to proceed with the master lease arrangement with Shenzhen Anju as certain conditions precedent under the agreement could not be satisfied. The Company formally terminated the agreement by issuing a termination notice to Shenzhen Anju in October 2026.

The Company continues to explore alternative leasing arrangements with other prospective tenants, including, among others, large-scale hotel groups and other institutional operators, with a view to ensuring the continued utilization of the relevant facilities.

Equity-for-Rent Initiative

To enhance tenant retention and create potential long-term value in a competitive leasing environment, the Company introduced a selective “equity-for-rent” arrangement at Nam Tai Inno Park in the second half of 2025. Under this model, the Company may, on a case-by-case basis and subject to strict commercial evaluation, exchange a portion of rental payments for minority equity interests in high-potential tenant companies. This approach allows the Company to align interests with selected tenants while participating in their potential future upside. In the first transaction under this model, relevant business registration was completed in February 2026, and the Company exchanged rental consideration for a minority equity stake in a qualifying tenant enterprise. The Company intends to apply this tool selectively to support occupancy stability and diversify revenue sources beyond traditional rental income, while maintaining disciplined valuation and risk management. This initiative is part of the Company’s ongoing efforts to strengthen its competitive position in the Greater Bay Area industrial property market. The Company expects to apply this initiative only selectively and does not intend for it to become a material investment activity.

Nam Tai Technology Center – Land Contract Obligations

In connection with delays in the development and completion of Nam Tai Technology Center, the Company continues to be in discussions with the relevant local authorities regarding its certain obligations under the project's land use rights grant contract, including potential contractual liabilities arising from delays in meeting specified development milestones.

The completion of Nam Tai Technology Center has been delayed by over 40 months beyond the deadline under the land use rights grant contract. The Company is seeking recognition by the relevant authorities of the relevant historical circumstances that contributed to the delays, including the COVID-19 pandemic, and is exploring possible reductions of its potential liabilities, although the extent of any such reduction, if any, is uncertain at this stage. The Company is also working toward a resolution that would facilitate the remaining property registration procedures.

As of the date of this report, the Company has not received a final determination or a formal payment notice from the relevant authorities regarding such obligations. The amount and timing of any potential payment or other obligations remain subject to discussions with the relevant authorities. The ultimate outcome could have a material adverse effect on the Company's financial condition, results of operations and liquidity, and could further delay the commercialization of Nam Tai Technology Center. Please refer to Part I, Item 3.D. “Risk Factors” in the Company's Annual Report on Form 20-F for factors relating to potential penalties or forfeiture of land under land use rights grant contracts.

FORWARD-LOOKING STATEMENTS AND FACTORS THAT COULD CAUSE OUR SHARE PRICE TO DECLINE

This report contains forward-looking statements about future expectations and plans, as well as other statements regarding matters that are not historical facts. These forward-looking statements are made under the “safe-harbor” provisions of the U.S. Private Securities Litigation Reform Act of 1995. These forward-looking statements include, but are not limited to, statements regarding the Company’s ongoing working capital management and liquidity position, the Company’s pursuit of additional external financing, the Company’s expectations regarding the use of proceeds under the RMB 700 million long-term refinancing of Nam Tai Inno Park with Ping An Bank and the RMB 40 million credit facility with Shenzhen Rural Commercial Bank for the Qianhai project as well as the Company’s ability to satisfy any remaining drawdown conditions under such financing facilities, the Company’s strategy to reduce inventory at Nam Tai • Longxi, the Company’s expectations regarding the generation of rental and sales revenue from Nam Tai Technology Center upon its completion, including the expected timing of such revenue, the expected completion timeline of Nam Tai Technology Center and the expected timing of the related construction completion acceptance and regulatory filings and registrations, the Company’s discussions with local authorities regarding its obligations under the land use rights grant contract for Nam Tai Technology Center, the Company’s ability to obtain recognition of the historical circumstances that contributed to the project delays and to reach a resolution of such matters, the amount and timing of any potential liabilities under such contract, the Company’s ability to satisfy the conditions for property pre-sales under applicable PRC regulations for the Nam Tai Technology Center, the Company’s revised plan to develop and market Tower C of Nam Tai Technology Center for sale rather than for leasing, the Company’s exploration of alternative leasing arrangements with prospective tenants following the termination of the master lease agreement with Shenzhen Anju, the Company’s intention to selectively apply the equity-for-rent arrangement to support occupancy stability and diversify revenue sources, the Company’s expectation that the equity-for-rent initiative will be applied only selectively and is not intended to become a material investment activity, the Company’s belief in its strategic direction and long-term value creation potential in the Greater Bay Area industrial property market, the Company’s belief on the invalidity of Guangshengda’s assignment of claims for Nam Tai • Longxi project under its general construction contract, the expected outcomes and timing of the Company’s pending legal and arbitration proceedings, including the Nam Tai • Longxi general contractor dispute and staged mortgage guarantee arbitrations, and statements with respect to the Company’s beliefs, plans, objectives, goals, expectations, anticipations, estimates, and intentions that are subject to significant risks and uncertainties and are subject to change based on various factors, many of which are beyond the Company’s control. These factors include risks related to its currently contemplated strategy, competition, timing, conditions in the PRC real estate market, including declines in property selling prices and transaction volumes, leasing demand and rental pressure in Shenzhen, the Company’s ability to attract and retain tenants and maintain occupancy levels, including its ability to secure replacement tenants for Nam Tai Technology Center, increases in costs of materials, capital and financing needs, access to funding under the Company’s debt instruments and the timing thereof, the Company’s ability to refinance certain debt and to comply with the covenants and conditions under its financing arrangements, its ability to sell certain assets, construction/development challenges or setbacks, further delays in the completion of Nam Tai Technology Center, its ability to hire and retain construction contractors and subcontractors, the Company’s ability to obtain materials and supplies necessary for construction of various projects, any unforeseen issues relating to construction, including environmental, weather, catastrophes, or other issues, the Company’s ability to obtain construction completion acceptance and the regulatory filings and registrations required for the sale of properties, the outcome of the Company’s discussions with local authorities regarding the land use rights grant contract for Nam Tai Technology Center, including the imposition of penalties or other payment obligations, or the forfeiture of land use rights, and the effect of any such payment on the Company’s liquidity and planned expenditures, the Company’s ability to add additional guaranteed power to certain of its projects, projected regional development, composition of potential tenants of development projects, development of asset light capabilities for internal or external use and monetization, judicial and regulatory challenges and/or delays, changes in economic policy, including in relation to trade and/or tariffs, anticipated savings or uses of funding from refinancings, changes in general economic conditions, and other factors detailed from time to time in the Company’s filings with the U.S. Securities and Exchange Commission (the “SEC”), including the risk factors discussed in the Company’s annual report on Form 20-F for the fiscal year ended December 31, 2025. You should not place undue reliance on forward-looking statements, which reflect management’s view only as of the date of this report. The words “may”, “could”, “can”, “should”, “would”, “will”, “believe”, “anticipate”, “estimate”, “expect”, “intend”, “plan”, “potential”, “seek”, “advance”, “strengthen”, “continue”, “remain”, “pursue” and similar expressions are intended to identify forward-looking statements. All forward-looking statements are based on information currently available to the Company, and the Company does not undertake to update any forward-looking statement, whether written or oral, whether as a result of new information, future events or otherwise, except as may be required by applicable law or regulations.

ABOUT NAM TAI PROPERTY INC.

Nam Tai Property Inc., a company incorporated in the British Virgin Islands (the “BVI”) and governed by BVI law, owns certain subsidiaries, that own and operate commercial real estate projects across the People’s Republic of China. Those subsidiaries currently maintain two industrial complex projects, with one in Guangming, Shenzhen and one in Bao’an, Shenzhen, as well as one residential project in Dongguan. Learn more about the Company and the portfolio of properties held by certain of its subsidiaries by emailing our investor relations team or visiting Weibo: https://weibo.com/u/7755634761.

NAM TAI PROPERTY INC.

CONDENSED CONSOLIDATED STATEMENTS OF COMPREHENSIVE INCOME

FOR THE PERIODS ENDED September 30, 2026 AND 2025

(In Thousands of US dollars except share and per share data)

Notes:

NAM TAI PROPERTY INC.

CONDENSED CONSOLIDATED BALANCE SHEETS

AS OF September 30, 2026 AND December 31, 2025

(In Thousands of US dollars)

Notes:

NAM TAI PROPERTY INC.

CONDENSED CONSOLIDATED STATEMENTS OF CASH FLOWS

FOR THE PERIODS ENDED September 30, 2026 AND 2025

(In Thousands of US dollars)

NAM TAI PROPERTY INC.

NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS

FOR THE PERIODS ENDED September 30, 2026 AND 2025

(In Thousands of US dollars)