As filed with the Securities and Exchange Commission on April 17, 2024

UNITED STATES
SECURITIES AND EXCHANGE COMMISSION
WASHINGTON, D.C. 20549

________________________

FORM S-1
REGISTRATION STATEMENT
UNDER
THE SECURITIES ACT OF 1933

________________________

ZEO ENERGY CORP.
(Exact name of registrant as specified in its charter)

________________________

7625 Little Rd, Suite 200A
New Port Richey, FL 34654
(727) 375-9375
(Address, including zip code, and telephone number, including area code, of registrant’s principal executive offices)

________________________

Timothy Bridgewater, Chief Executive Officer
7625 Little Rd, Suite 200A
New Port Richey, FL 34654
(727) 375-9375
(Name, address, including zip code, and telephone number, including area code, of agent for service)

________________________

Copies to:
Stuart Neuhauser, Esq.
Adam Berkaw, Esq.
Ellenoff Grossman & Schole LLP
1345 6th Ave
New York, NY 10105
Tel: (212) 370-1300

________________________

Approximate date of commencement of proposed sale to the public: As soon as practicable after the effective date of this Registration Statement.

If any of the securities being registered on this Form are to be offered on a delayed or continuous basis pursuant to Rule 415 under the Securities Act of 1933, check the following box. ☒

If this Form is filed to register additional securities for an offering pursuant to Rule 462(b) under the Securities Act, check the following box and list the Securities Act registration statement number of the earlier effective registration statement for the same offering. ☐

If this Form is a post-effective amendment filed pursuant to Rule 462(c) under the Securities Act, check the following box and list the Securities Act registration statement number of the earlier effective registration statement for the same offering. ☐

If this Form is a post-effective amendment filed pursuant to Rule 462(d) under the Securities Act, check the following box and list the Securities Act registration statement number of the earlier effective registration statement for the same offering. ☐

Indicate by check mark whether the registrant is a large accelerated filer, an accelerated filer, a non-accelerated filer, a smaller reporting company or an emerging growth company. See the definitions of “large accelerated filer,” “accelerated filer,” “smaller reporting company” and “emerging growth company” in Rule 12b-2 of the Exchange Act. ☐

If an emerging growth company, indicate by check mark if the registrant has elected not to use the extended transition period for complying with any new or revised financial accounting standards provided pursuant to Section 7(a)(2)(B) of the Securities Act. ☐

Rule 429 Statement

Pursuant to Rule 429 under the Securities Act, the prospectus contained in this Registration Statement on Form S-1 (referred to herein as the Registration Statement) will be used as a combined prospectus in connection with this Registration Statement and the registrant’s Registration Statement on Form S-4 (File No. 333-274551), that was originally declared effective by the Securities and Exchange Commission on February 13, 2024 (as amended, the “Prior Registration Statement”). Accordingly, this Registration Statement also constitutes Post-Effective Amendment No. 1 on Form S-4 to the Prior Registration Statement. Such Post-Effective Amendment will become effective concurrently with the effectiveness of this Registration Statement in accordance with Section 8(c) of the Securities Act.

The Registrant hereby amends this Registration Statement on such date or dates as may be necessary to delay its effective date until the Registrant shall file a further amendment which specifically states that this Registration Statement shall thereafter become effective in accordance with Section 8(a) of the Securities Act of 1933, as amended, or until the Registration Statement shall become effective on such date as the Commission, acting pursuant to said Section 8(a), may determine.

The information in this prospectus is not complete and may be changed. We may not sell these securities until the registration statement filed with the Securities and Exchange Commission is effective. This prospectus is not an offer to sell these securities and it is not soliciting an offer to buy these securities in any state where the offer or sale is not permitted.

TABLE OF CONTENTS

ABOUT THIS PROSPECTUS

This prospectus is part of a registration statement on Form S-1 that we filed with the SEC using the “shelf” registration process. Under the shelf registration process, the selling securityholders may, from time to time, sell the securities offered by them described in this prospectus through any means described in the section titled “Plan of Distribution.” More specific terms of any securities that the selling securityholders and their permitted transferees offer and sell may be provided in a prospectus supplement that describes, among other things, the specific amounts and prices of the securities being offered and the terms of the offering. This prospectus also relates to the issuance by us of shares of Class A Common Stock from time to time upon the occurrence of the events described in this prospectus.

We may also provide a prospectus supplement or post-effective amendment to the registration statement of which this prospectus forms a part to add information to, or update or change information contained in, this prospectus. Any statement contained in this prospectus will be deemed to be modified or superseded for purposes of this prospectus to the extent that a statement contained in such prospectus supplement or post-effective amendment modifies or supersedes such statement. Any statement so modified will be deemed to constitute a part of this prospectus only as so modified, and any statement so superseded will be deemed not to constitute a part of this prospectus. You should read both this prospectus and any applicable prospectus supplement or post-effective amendment to the registration statement of which this prospectus forms a part together with the additional information to which we refer you in the sections of this prospectus titled “Where You Can Find More Information.”

This prospectus contains summaries of certain provisions contained in some of the documents described herein, but reference is made to the actual documents for complete information. All of the summaries are qualified in their entirety by the actual documents. Copies of some of the documents referred to herein have been filed, will be filed, or will be incorporated by reference as exhibits to the registration statement of which this prospectus forms a part, and you may obtain copies of those documents as described under “Where You Can Find More Information.”

As used in this prospectus, unless otherwise indicated or the context otherwise requires, references to “we,” “us,” “our,” the “Company,” “Registrant,” and “Zeo” refer to Zeo Energy Corp. following the Business Combination and Sunergy Renewables, LLC prior to the Business Combination.

INDUSTRY AND MARKET DATA

This prospectus contains, and any amendment or any prospectus supplement may contain, industry and market data which have been obtained from industry publications, market research and other publicly available information. Such information is supplemented, where necessary, with the Company’s own internal estimates, taking into account publicly available information about other industry participants and the judgment of the Company’s management where information is not publicly available.

Industry publications and market research generally state that the information they contain has been obtained from sources believed to be reliable, but that the accuracy and completeness of such information is not guaranteed and that the projections they contain are based on a number of significant assumptions. In some cases, the sources from which this data is derived is not expressly referred to. While the Company compiled, extracted and reproduced industry data from these sources, and believes that the information used is reliable, the Company did not independently verify the data that was extracted or derived from such industry publications or market reports, and cannot guarantee its accuracy or completeness.

The industry and market data that appears in this prospectus is inherently uncertain, involves a number of assumptions and limitations and may not necessarily be reflective of actual market conditions and you are cautioned not to give undue weight to such industry and market data because it may differ from current data due to material changes in market conditions or otherwise. Such statistics are based on market research, which itself is based on sampling and subjective judgements by both the researchers and the respondents, including judgements about what types of products and transactions should be included in the relevant market. Forecasts and other forward-looking information obtained from these sources are subject to the same qualifications and uncertainties as the other forward-looking statements in this prospectus. These and other factors could cause results to differ materially from those expressed in any forecasts or estimates.

The Company does not intend or assume any obligation to update industry or market data set forth in this prospectus. Because market behavior, preferences and trends are subject to change, prospective investors should be aware that market and industry information in this prospectus and estimates based on any data therein may not be reliable indicators of future market performance or the Company’s future results of operations.

TRADEMARKS

This prospectus contains, and any amendment or any prospectus supplement may contain, references to trademarks and service marks belonging to other entities. Solely for convenience, trademarks and trade names, referred to in this prospectus may appear without the ® or ™ symbols, but such references are not intended to indicate, in any way, that the applicable licensor will not assert, to the fullest extent under applicable law, its rights to these trademarks and trade names. We do not intend our use or display of other companies’ trade names, trademarks or service marks to imply a relationship with, or endorsement or sponsorship of us by, any other companies.

FREQUENTLY USED TERMS AND BASIS OF PRESENTATION

As used in this prospectus, unless otherwise noted or the context otherwise requires, references to:

When used in this proxy statement/prospectus, unless the context otherwise requires:

•        “2024 Plan” refers to the 2024 Omnibus Incentive Equity Plan of Zeo.

•        “A&R Registration Rights Agreement” refers to the Amended and Restated Registration Rights Agreement entered into at Closing, by Zeo, the Sponsor, Piper, the holders of ESGEN Class B ordinary shares and the Sellers pursuant to which, among other things, the Sponsor, Piper, the holders of ESGEN Class B ordinary shares and the Sellers were granted certain registration rights with respect to their respective shares of Common Stock, in each case, on the terms and subject to the conditions set forth therein.

•        “affiliate” refers to, with respect to any Person, any other Person who directly or indirectly, through one or more intermediaries, controls, is controlled by, or is under common control with, such Person. The term “control” means the possession, directly or indirectly, of the power to direct or cause the direction of the management and policies of a Person, whether through the ownership of voting securities, by contract or otherwise, and the terms “controlled” and “controlling” have meanings correlative thereto.

•        “Amendment to the Letter Agreement” refers to the agreement entered into by the Sponsor, the independent directors of ESGEN and the Westwood Client Accounts, dated April 19, 2023, which was subsequently amended and restated on January 24, 2024 (as amended from time to time).

•        “Board” refers to the board of directors of Zeo.

•        “Business Combination” refers to the transactions contemplated by the Business Combination Agreement.

•        “Business Combination Agreement” refers to the Business Combination Agreement dated as of April 19, 2023, as amended by the First Amendment thereto, dated as of January 24, 2024, by and among ESGEN, Sunergy, OpCo, the Sellers, the Sponsor, for the limited purposes set forth therein, and Timothy Bridgewater, an individual, in his capacity as the Sellers Representative.

•        “Bylaws” refers to the new bylaws of Zeo adopted in connection with the Business Combination.

•        “Charter” refers to the certificate of incorporation of Zeo adopted in connection with the Business Combination.

•        “Class A Common Stock” refers to shares of Class A common stock, par value $0.0001 per share, of Zeo.

•        “Class V Common Stock” refers to shares of Class V common stock, par value $0.0001 per share, of Zeo.

•        “Closing” refers to the closing of the Business Combination.

•        “Closing Date” refers to the date on which the Business Combination closed, March 13, 2024.

•        “Common Stock” refers to the collective shares of Class A Common Stock and Class V Common Stock.

•        “Convertible OpCo Preferred Unit Conversion” refers to a Convertible OpCo Preferred Unit Optional Conversion, Convertible OpCo Preferred Unit Maturity Date Conversion, and Convertible OpCo Preferred Unit Transaction Event Conversion, collectively.

•        “Convertible OpCo Preferred Unit Dividend Payment Date” refers to the last day of March, June, September and December of each calendar year during which the Convertible OpCo Preferred Units are outstanding.

•        “Convertible OpCo Preferred Unit Maturity Date” means the date that is three (3) years following the Closing Date.

•        “Convertible OpCo Preferred Unit Maturity Date Conversion” refers to the conversion of all, but not less than all, Convertible OpCo Preferred Units into an amount of Exchangeable OpCo Units as is determined by dividing the Convertible OpCo Preferred Unit Original Issue Price plus the aggregate accumulated and unpaid Convertible OpCo Preferred Unit Accruing Dividends with respect to such Convertible OpCo Preferred Units, if any, through the date the conversion occurs, by a weighted average of the daily market price of the Class A Common Stock during the five (5) trading days prior to the date thereof, upon the Convertible OpCo Preferred Unit Maturity Date, subject to certain restrictions set forth in the OpCo A&R LLC Agreement, followed by an immediate exchange of such Exchangeable OpCo Units (together with an equal number of shares of Class V Common Stock) into an equal number of shares of Class A Common Stock.

•        “Convertible OpCo Preferred Unit Optional Conversion” refers to the conversion of all, but not less than all, Convertible OpCo Preferred Units, into an amount of Exchangeable OpCo Units as is determined by dividing the Convertible OpCo Preferred Unit Original Issue Price plus the aggregate accumulated and unpaid Convertible OpCo Preferred Unit Accruing Dividends with respect to such Convertible OpCo Preferred Units, if any, through the date the conversion occurs, by $11.00, at the option of Sponsor, subject to certain restrictions set forth in the OpCo A&R LLC Agreement, followed by an immediate exchange of such Exchangeable OpCo Units (together with an equal number of shares of Class V Common Stock) into an equal number of shares of Class A Common Stock.

•        “Convertible OpCo Preferred Unit Redemption” refers to a Convertible OpCo Preferred Unit Required Redemption and Convertible OpCo Preferred Unit Put Option Redemption, collectively.

•        “Convertible OpCo Preferred Unit Transaction Event Conversion” refers to, in the event of certain change of control transactions or qualified financings, the conversion of all, but not less than all, Convertible OpCo Preferred Units, into an amount of Exchangeable OpCo Units as is determined by dividing the Convertible OpCo Preferred Unit Original Issue Price plus the aggregate accumulated and unpaid Convertible OpCo Preferred Unit Accruing Dividends with respect to such Convertible OpCo Preferred Units, if any, through the date the conversion occurs, by $11.00, at the option of Sponsor, subject to certain restrictions set forth in the OpCo A&R LLC Agreement, followed by an immediate exchange of such Exchangeable OpCo Units (together with an equal number of shares of Class V Common Stock) into an equal number of shares of Class A Common Stock.

•        “Convertible OpCo Preferred Unit Original Issue Price” refers to $10.00.

•        “Convertible OpCo Preferred Units” refers to the Class A OpCo convertible preferred units issued to the Sponsor pursuant to the Sponsor Subscription Agreement.

•        “CST” refers to Continental Stock Transfer & Trust Company.

•        “Domestication” refers to the continuation of ESGEN by way of domestication of ESGEN into a Delaware corporation, with the ESGEN ordinary shares becoming shares of common stock of the Delaware corporation under the applicable provisions of the Cayman Islands Companies Act (As Revised) and the DGCL; the term includes all matters and necessary or ancillary changes in order to effect such Domestication, including the adoption of the Charter consistent with the DGCL and changing the name and registered office of ESGEN.

•        “DTC” refers to Depository Trust Company.

•        “Early Lock-Up Termination” refers to the termination of the lock-up period under the Amendment to the Letter Agreement when, subsequent to Closing, the last sale price of Class A Common Stock quoted on Nasdaq is greater than or equal to $12 per share (as adjusted for stock splits, stock dividends, reorganizations, recapitalizations and the like) for any 20 trading days within a 30-consecutive trading day period commencing at least 90 days after Closing.

•        “Energy Spectrum” refers to Energy Spectrum Partners VIII LP.

•        “ESGEN” refers to ESGEN Acquisition Corporation, a former blank check company incorporated as a Cayman Islands exempt company.

•        “ESGEN Class A ordinary shares” refers to the Class A ordinary shares, par value $0.0001 per share, of ESGEN.

•        “ESGEN Class B ordinary shares” refers to the Class B ordinary shares, par value $0.0001 per share, of ESGEN.

•        “ESGEN ordinary shares” refers to ESGEN Class A ordinary shares and ESGEN Class B ordinary shares.

•        “ESGEN Private Placement Warrants” refers to the warrants to purchase ESGEN Class A ordinary shares that were issued to the Initial Shareholders in a private placement concurrently with the IPO.

•        “ESGEN Public Warrants” refers to the redeemable warrants issued in the IPO, entitling the holder thereof to purchase ESGEN Class A ordinary shares.

•        “ESGEN Share Conversion” refers to the conversion of each ESGEN Class B ordinary share into one ESGEN Class A ordinary share prior to the Domestication.

•        “ESGEN Warrants” refers collectively to the ESGEN Private Placement Warrants together with the ESGEN Public Warrants.

•        “Exchange Act” refers to the Securities Exchange Act of 1934, as amended.

•        “Exchangeable OpCo Units” refers to the Class B units of OpCo.

•        “FASB” refers to the Financial Accounting Standards Board.

•        “Initial Shareholders” collectively refers to the Sponsor, ESGEN’s former four independent directors who held ESGEN Class B ordinary shares and the Westwood Client Accounts.

•        “Investment Company Act” refers to the Investment Company Act of 1940, as amended.

•        “IPO” refers to ESGEN’s initial public offering of its ESGEN Class A ordinary shares (the “Public Shares”) and ESGEN Public Warrants pursuant to the ESGEN’s Registration Statement on Form S-1, filed with the SEC (File No. 333-252730), on September 28, 2021, and completed on October 22, 2021.

•        “Lock-Up Agreement” refers to the lock-up agreement entered into in connection with the Closing between the Sellers and Zeo.

•        “Mandatory Exchange” refers to Zeo’s right to require, (i) upon a Change of Control Transaction (as defined in the OpCo A&R LLC Agreement) or (ii) in the discretion of Zeo, with the consent of holders of the OpCo Units holding more than 72% of the OpCo Units (excluding OpCo Units held by Zeo), each holder of Exchangeable OpCo Units to exchange all of its Exchangeable OpCo Units.

•        “Nasdaq” refers to the Nasdaq Stock Market.

•        “OpCo” refers to ESGEN OpCo, LLC, a Delaware limited liability company.

•        “OpCo A&R LLC Agreement” refers to the Amended and Restated Limited Liability Company Agreement of OpCo.

•        “OpCo Exchange Right” refers to the rights of holders of Exchangeable OpCo Units to cause OpCo to redeem one or more of such Exchangeable OpCo Units, together with the cancellation of an equal number of shares of such holder’s Seller Class V Common Stock, for shares of Class A Common Stock on a one-for-one basis, or, at the election of Zeo (as manager of OpCo), cash.

•        “OpCo Manager Units” refers to the Class A units of OpCo issued to Zeo in connection with the Business Combination.

•        “OpCo Units” refers to the Exchangeable OpCo Units and the OpCo Manager Units, collectively.

•        “Organizational Documents” refers to the Charter and the Bylaws of Zeo.

•        “Person” means an individual, corporation, partnership, limited partnership, limited liability company, person (including, without limitation, a “person” as defined in Section 13(d)(3) of the Exchange Act), trust, association or entity or government, political subdivision, agency or instrumentality of a government.

•        “Sarbanes-Oxley Act” refers to the Sarbanes-Oxley Act of 2002.

•        “SEC” refers to the U.S. Securities and Exchange Commission.

•        “Securities Act” refers to the Securities Act of 1933, as amended.

•        “Seller Class V Common Stock” refers to a number of newly issued shares of Class V Common Stock, equal to the number of Exchangeable OpCo Units, issued to the Sellers by OpCo in exchange for the Sellers’ contribution of the Sunergy Company Interests to OpCo in connection with the Business Combination.

•        “Sellers” refers to the holders of the Sunergy Company Interests immediately prior to the Closing of the Business Combination.

•        “Sponsor” refers to ESGEN LLC, a Delaware limited liability company.

•        “Sponsor Forfeited Shares” refers to the 2,361,641 ESGEN ordinary shares forfeited by the Sponsor at Closing pursuant to the Letter Agreement Amendment.

•        “Sponsor PIPE Investment” refers to the Sponsor’s commitment to purchase an aggregate of 1,000,000 Convertible OpCo Preferred Units concurrently with the Closing at a cash purchase price of $10.00 per share, and up to an additional 500,000 Convertible OpCo Preferred Units during the six months after Closing if called for by Zeo.

•        “Sponsor PIPE Securities” refers to the 1,000,000 Convertible OpCo Preferred Units and up to an additional 500,000 Convertible OpCo Preferred Units during the six months after Closing if called for by Zeo, to be sold to the Sponsor pursuant to the Sponsor Subscription Agreement.

•        “Sponsor Subscription Agreement” refers to that certain subscription agreement, dated as of April 19, 2023, which was subsequently amended and restated on January 24, 2024, by and between ESGEN, OpCo and the Sponsor, entered into in connection with the Business Combination Agreement.

•        “Sunergy” refers to Sunergy Renewables, LLC, a Nevada limited liability company.

•        “Sunergy Company Interests” refers to the limited liability company interests of Sunergy.

•        “Sunergy Convertible Interests” refers to any options, warrants or rights to subscribe for or purchase any equity interests of Sunergy or any subsidiary of Sunergy or securities (including debt securities) convertible into or exchangeable for, or that otherwise confer on the holder any right to acquire, any equity interests of Sunergy or any subsidiary thereof.

•        “Tax Receivable Agreement” refers to the tax receivable agreement that Zeo entered into with the Sellers in connection with the Closing.

•        “TRA Holders” refers to the persons from time to time that become a party to the Tax Receivable Agreement.

•        “Trust Account” refers to the trust account of ESGEN which held the net proceeds from the IPO and certain of the proceeds received in respect of the sale of the ESGEN Private Placement Warrants, together with interest earned thereon, less amounts released to pay taxes.

•        “U.S. Holder” has the meaning set forth in “Material U.S. Federal Income Tax Considerations — U.S. Holders.”

•        “Warrants” refers to the redeemable warrants issued in the IPO, entitling the holder thereof following completion of the Domestication to purchase Class A Common Stock.

•        “Westwood Client Accounts” refers to one or more client accounts of Westwood Holdings Group, Inc., a Delaware corporation, the successor to Salient Capital Partners, LLC, a Texas limited liability company, that purchased ESGEN Class B ordinary shares and ESGEN Private Placement Warrants concurrently with the IPO.

•        “Zeo” refers to Zeo Energy Corp., a Delaware corporation.

Unless specified otherwise, amounts in this prospectus are presented in U.S. dollars.

Defined terms in the financial statements contained in this prospectus have the meanings ascribed to them in the financial statements.

CAUTIONARY STATEMENT REGARDING FORWARD-LOOKING STATEMENTS

This prospectus contains forward-looking statements for purposes of the safe harbor provisions under the United States Private Securities Litigation Reform Act of 1995, including statements regarding, among other things, the plans, strategies and prospects, both business and financial, of the Company. These statements are based on the beliefs and assumptions, whether or not identified in this prospectus, of the management of the Company. Although the Company believes that its plans, intentions and expectations reflected in or suggested by these forward-looking statements are reasonable, the Company cannot assure you that it will achieve or realize these plans, intentions or expectations. Forward-looking statements are inherently subject to risks, uncertainties and assumptions. Generally, statements that are not historical facts, including statements concerning possible or assumed future actions, business strategies, events or results of operations, and any statements that refer to projections, forecasts or other characterizations of future events or circumstances, including any underlying assumptions, are forward-looking statements. These statements may be preceded by, followed by or include the words “anticipate,” “believe,” “could,” “continue,” “estimate,” “expect,” “forecast,” “intend,” “may,” “might,” “plan,” “possible,” “potential,” “project,” “scheduled,” “seek,” “should,” “will” or similar expressions, but the absence of these words does not mean that a statement is not forward-looking. Forward-looking statements contained in this prospectus include, but are not limited to, statements about the ability of the Company to:

•        the failure to realize the anticipated benefits of the Business Combination, which may be affected by, among other things, competition, the ability of Zeo to grow and manage growth profitably, maintain relationships with customers and suppliers and retain key employees;

•        the outcome of any legal proceedings that may be instituted in connection with the Business Combination;

•        our success in retaining or recruiting our principal officers, key employees or directors;

•        intense competition and competitive pressures from electric utilities and other companies in the industry in which Zeo operates;

•        factors relating to the business, operations and financial performance of Zeo, including market conditions and global and economic factors beyond Zeo’s control;

•        changes in general economic conditions, including unemployment, inflation (including the impact of tariffs) or deflation, financial institution disruptions and geopolitical conflicts such as the conflict between Russia and Ukraine and the conflict in the Gaza Strip;

•        the reduction or elimination of government economic incentives to the renewable energy market;

•        the ability of Zeo to issue equity or equity-linked securities or obtain debt financing;

•        the demand for renewable energy not being sustained or growing in size;

•        impacts of climate change, changing weather patterns and conditions and natural disasters;

•        increases in costs of solar energy system components and raw materials;

•        loss of a supplier or other supply chain disruptions;

•        problems with the quality or performance of the solar energy systems that Zeo sells;

•        the effect of legal, tax and regulatory changes; and

•        each of the other factors detailed under the section entitled “Risk Factors.”

Forward-looking statements are provided for illustrative purposes only and are not guarantees of performance. You should not put undue reliance on these statements which speak only as of the date hereof. You should understand that the factors discussed under the heading “Risk Factors” and elsewhere in this prospectus, could affect the future results of the Company, and could cause those results or other outcomes to differ materially from those expressed or implied in the forward-looking statements in this prospectus.

In addition, the risks described under the heading “Risk Factors” are not exhaustive. Other sections of this prospectus describe additional factors that could adversely affect the businesses, financial conditions, or results of operations of the Company. New risk factors emerge from time to time and it is not possible to predict all such risk factors, nor can the Company assess the impact of all such risk factors on the business of the Company, or the extent to which any factor or combination of factors may cause actual results to differ materially from those contained in any forward-looking statements. All forward-looking statements attributable to the Company or persons acting on their behalf are expressly qualified in their entirety by the foregoing cautionary statements. The Company undertakes no obligations to update or revise publicly any forward-looking statements, whether as a result of new information, future events or otherwise, except as required by law.

In addition, this prospectus contains statements of belief and similar statements that reflect the beliefs and opinions of the Company on the relevant subject. These statements are based upon information available to the Company as of the date of this prospectus, and while the Company believes such information forms a reasonable basis for such statements, such information may be limited or incomplete, and statements should not be read to indicate that the Company has conducted an exhaustive inquiry into, or review of, all potentially available relevant information. These statements are inherently uncertain and you are cautioned not to unduly rely upon these statements.

RISK FACTORS

Investing in our securities involves risks. Before you make a decision to buy our securities, in addition to the risks and uncertainties discussed above under “Cautionary Note Regarding Forward-Looking Statements,” you should carefully consider the specific risks set forth herein. If any of these risks actually occur, it may materially harm our business, financial condition, liquidity and results of operations. As a result, the market price of our securities could decline, and you could lose all or part of your investment. Additionally, the risks and uncertainties described in this prospectus or any prospectus supplement are not the only risks and uncertainties that we face. We may face additional risks and uncertainties that are not presently known to us, or that we currently deem immaterial, which may also impair our business, prospects, financial condition or operating results. The following discussion should be read in conjunction with our financial statements and notes to the financial statements included herein.

Risks Related to the Solar Industry

The solar energy industry is an emerging market which is constantly evolving and additional demand for solar energy systems may not develop to the size or at the rate we expect.

The solar energy industry is an emerging and constantly evolving market opportunity. We believe the solar energy industry is still developing and maturing, and we cannot be certain that additional demand for solar energy systems will grow to the size or at the rate we expect. Any future growth of the solar energy market and the success of our solar service offerings depend on many factors beyond our control, including recognition and acceptance of the solar service market by consumers, the pricing of alternative sources of energy, a favorable regulatory environment, the continuation of expected tax benefits and other incentives, and our ability to provide our solar service offerings cost effectively. If additional demand for solar energy systems does not develop to the size or at the rate we expect, our business may be adversely affected.

Solar energy has yet to achieve broad market acceptance and depends in part on continued support in the form of rebates, tax credits, and other incentives from federal, state and local governments or utilities. If support diminishes materially for solar policy related to rebates, tax credits and other incentives, demand for our products and services may decrease and our ability to obtain external financing on acceptable terms, or at all, could be materially adversely affected. These types of funding limitations could lead to inadequate financing support for the anticipated growth in our business. Furthermore, growth in residential solar energy depends in part on macroeconomic conditions, retail prices of electricity and customer preferences, each of which can change quickly. Declining macroeconomic conditions, including in the job markets and residential real estate markets, could contribute to instability and uncertainty among customers and impact their financial wherewithal, credit scores or interest in entering into long-term contracts, even if such contracts would generate immediate and/or long-term savings.

Furthermore, market prices of retail electricity generated by utilities or other energy sources could decline for a variety of reasons, as discussed further below. Any such declines in macroeconomic conditions, changes in retail prices of electricity or changes in customer preferences would adversely impact our business.

At the international level, the United Nations-sponsored Paris Agreement requires member states, including the United States, to submit non-binding, individually-determined greenhouse gas reduction goals known as “Nationally Determined Contributions” every five years after 2020. President Biden has committed the United States to a goal of reducing greenhouse gas emissions by 50 – 52% below 2005 levels by 2030, a target consistent with the Paris Agreement’s goal of “net-zero” greenhouse gas emissions by 2050. “Net zero” means that the amount of greenhouse gases emitted into the atmosphere are balanced by an equal amount of greenhouse gases being removed from the atmosphere. Achieving net zero emissions by 2050 will require an unprecedented transformation of American energy systems and the adoption of a wide variety of clean energy, storage, and home electrification solutions. Our successful deployment of such products will depend on several factors outside our control, including shifting market conditions and policy frameworks. Our failure to adapt to changing market conditions, to compete successfully with existing or new competitors, and to adopt new or enhanced offerings could limit our growth and have a material adverse effect on our business and prospects. Further, additional international agreements or any legislation, regulation, or executive action within the U.S. addressing climate change, including any climate-related disclosure requirements and legislation or regulation intended to support the goals of the Paris Agreement, may in the future result in increases in our compliance costs and other operating costs. Finally, if the United States were to exit the Paris Agreement, support from the U.S. government and, as a result, consumer demand, may decrease.

We face competition from electric utilities, retail electric providers, independent power producers, renewable energy companies and other market participants.

The solar energy and renewable energy industries are both highly competitive and continually evolving as participants strive to distinguish themselves within their markets and compete with large electric utilities. We believe our primary competitors are the electric utilities that supply electricity to our potential customers. We compete with these electric utilities primarily based on price (cents per kWh), predictability of future prices (by providing pre-determined annual price escalations) and the ease by which customers can switch to electricity generated by our solar energy systems. We may also compete based on other value-added benefits, such as reliability and carbon-friendly power. If we cannot offer compelling value to our customers based on these factors, our business may not grow.

Electric utilities generally have substantially greater financial, technical, operational and other resources than we do. As a result, these competitors may be able to devote more resources to the research, development, promotion and sale of their products or services or respond more quickly to evolving industry standards and changes in market conditions than we can. Electric utilities could also offer other value-added products or services that could help them to compete with us even if the cost of electricity they offer is higher than ours. In addition, a majority of utilities’ sources of electricity is non-solar, which may allow utilities to sell electricity more cheaply than electricity generated by our solar energy systems. Electric utilities could also offer customers the option of purchasing electricity obtained from renewable energy resources, including solar, which would compete with our offerings. Moreover, regulated utilities are increasingly seeking approval to “rate-base” their own solar energy system and energy storage system businesses. Rate-basing means that utilities would receive guaranteed rates of return for their solar energy system and energy storage system businesses. This is already commonplace for utility-scale solar projects and commercial solar projects. While few utilities to date have received regulatory permission to rate-base residential solar energy systems or energy storage systems, our competitiveness would be significantly harmed should more utilities receive such permission because we do not receive guaranteed profits for our solar service offerings.

We also compete with retail electric providers and independent power producers not regulated like electric utilities but which have access to the utilities’ electricity transmission and distribution infrastructure pursuant to state, territorial and local pro-competition and consumer choice policies. These retail electric providers and independent power producers are able to offer customers electricity supply-only solutions that are competitive with our solar energy system options on both price and usage of renewable energy technology while avoiding the physical installations our current business model requires. This may limit our ability to acquire new customers, particularly those who have an aesthetic or other objection to putting solar panels on their roofs.

We also compete with solar companies with vertically integrated business models like our own. For example, some of our competitors offer their own consumer financing products to customers and/or produce one or more components of the solar energy system or energy storage system. In addition to financing and manufacturing, some other business models also include sales, engineering, installation, maintenance and monitoring services. Many of our vertically integrated competitors are larger than we are and offer certain vertical services that we do not. As a result, these competitors may be able to devote more resources to the research, development, promotion and sale of their products or services or respond more quickly to evolving industry standards and changes in market conditions than we can. Solar companies with vertically integrated business models could also offer other value-added products or services that could help them to compete with us. Larger competitors may also be able to access financing at a lower cost of capital than we are able to obtain.

In addition, we compete with other residential solar companies who sell or finance products directly to consumers, inclusive of programs like Property-Assessed Clean Energy financing programs established by local governments. For example, we face competition from solar installation businesses that seek financing from external parties or utilize competitive loan products or state and local programs.

We also compete with solar companies that are marketed to potential customers by dealers, and we may also face competition from new entrants into the market as a result of the passage of the Inflation Reduction Act of 2022 (the “IRA”) and its anticipated impacts and benefits to the solar industry. Some of these competitors specialize in the distributed solar energy market and some may provide energy at lower costs than we do. Some of our competitors offer or may offer similar services and products as we do, such as direct outright sales of solar energy systems. Many of our competitors also have significant brand name recognition, lower barriers to entry into the solar market, greater capital resources than we have and extensive knowledge of our target markets. In addition, some of our competitors have an established business of providing construction, electrical contracting, or roofing services.

We also compete with community solar products offered by solar companies or sponsored by local governments and municipal power companies, as well as utility companies that provide renewable power purchase programs. Some customers might choose to subscribe to a community solar project or renewable subscriber programs instead of having a solar energy system installed on their home or business, which could affect our sales. Additionally, some utility companies (and some utility-like entities, such as community choice aggregators) have generation portfolios that are increasingly renewable in nature. As utility companies offer increasingly renewable portfolios to retail customers, those customers might be less inclined to have a solar energy system installed on their home or business, which could adversely affect our growth.

We have historically provided our services only to residential customers, but we may expand to other markets, including commercial and industrial customers. There is intense competition in the solar energy sector in the markets in which we operate and the markets into which we may expand. As new entrants continue to enter into these markets, and as we enter into new markets, we may be unable to grow or maintain our operations and we may be unable to compete with companies that have already established themselves in both the residential market and non-residential market.

As the solar industry grows and evolves, we will also face new competitors and technologies who are not currently in the market (including those resulting from the consolidation of existing competitors). Our industry is characterized by low technological barriers to entry, and well-capitalized companies, including utilities and integrated energy companies, could choose to enter the market and compete with us. Our failure to adapt to changing market conditions and to compete successfully with existing or new competitors will limit our growth and will have a material adverse effect on our business, financial condition and results of operations.

A material reduction in the retail price of electricity charged by electric utilities or other retail electricity providers would harm our business, financial condition and results of operations.

Decreases in the retail price of electricity from electric utilities or from other retail electric providers, including other renewable energy sources such as larger-scale solar energy systems, could make our offerings less economically attractive. The price of electricity from utilities could decrease as a result of:

•        the construction of a significant number of new power generation plants, whether generated by natural gas, nuclear power, coal or renewable energy;

•        the construction of additional electric transmission and distribution lines;

•        a reduction in the price of natural gas or other natural resources as a result of increased supply due to new drilling techniques or other technological developments, a relaxation of associated regulatory standards or broader economic or policy developments;

•        less demand for electricity due to energy conservation technologies and public initiatives to reduce electricity consumption or to recessionary economic conditions; and

•        development of competing energy technologies that provide less expensive energy.

A reduction in electric utilities’ rates or changes to peak hour pricing policies or rate design (such as the adoption of a fixed or flat rate) could also make our offerings less competitive with the price of electricity from the electrical grid. If the cost of energy available from electric utilities or other providers were to decrease relative to solar energy generated from solar energy systems or if similar events impacting the economics of our offerings were to occur, we may have difficulty attracting new customers. For example, large utilities in some states have started transitioning customers to time-of-use rates and also have adopted a shift in the peak period for time-of-use rates to later in the day. Unless grandfathered under a different rate, customers with solar energy systems may be required to take service under time-of-use rates with the later peak period. Moving utility customers to time-of-use rates or the shift in the timing of peak rates for utility-generated electricity to include times of day when solar energy generation is less efficient or non-operable could also make our offerings less competitive. Time-of-use rates could also result in higher costs for our customers whose electricity requirements are not fully met by our offerings during peak periods.

Sales and installation of solar energy systems depend heavily on suitable meteorological and environmental conditions. If meteorological or environmental conditions are unexpectedly unfavorable, the electricity production from our solar service offerings may be below our expectations, and our ability to timely deploy new systems may be adversely impacted.

The energy produced and revenue and cash flows generated by a solar energy system depend on suitable solar and weather conditions, both of which are beyond our control. Furthermore, components of our systems, such as panels and inverters, could be damaged by severe weather or natural catastrophes, such as hailstorms, tornadoes, fires, or earthquakes. Homeowner insurance or homeowners generally bear the expense of repairing weather-related damage to solar energy systems. However, in these circumstances, we make our install teams available to remove, repair and reinstall the systems. Sustained unfavorable weather or environmental conditions also could unexpectedly delay the installation of our solar energy systems, leading to increased expenses and decreased revenue and cash flows in the relevant periods. Extreme weather conditions, including those associated with climate change, as well as the natural catastrophes that could result from such conditions, can severely impact our operations by delaying the installation of our systems, lowering sales, and causing a decrease in the output from our systems due to smoke or haze. Weather patterns could change, making it harder to predict the average annual amount of sunlight striking each location where our solar energy systems are installed. This could make our solar service offerings less economical overall or make individual systems less economical. Our economic model and projected returns on our solar energy systems require achievement of certain production results from our systems and, in some cases, we guarantee these results to our consumers. If the solar energy systems underperform for any reason, our business could suffer. Any of these events or conditions could harm our business, financial condition, and results of operations.

Climate change may have long-term impacts on our business, our industry, and the global economy.

Climate change poses a systemic threat to the global economy, and we believe it will continue to do so until our society transitions to renewable energy and decarbonizes. While our core business model seeks to accelerate this transition to renewable energy, there are inherent climate-related risks to our business operations. Warming temperatures throughout the United States, including Florida, our biggest market, have contributed to extreme weather, intense drought, and increased wildfire risks. These events have the potential to disrupt our business, the operations of our third-party suppliers, and our customers, and may cause us to incur additional operational costs. For instance, natural disasters and extreme weather events associated with climate change can impact our operations by delaying the installation of our systems, leading to increased expenses and decreased revenue and cash flows. They can also cause a decrease in the output from our systems due to smoke or haze. Additionally, if weather patterns significantly shift due to climate change, it may be harder to predict the average annual amount of sunlight striking each location where our solar energy systems are installed and energy output from our systems could be reduced in the short-term or long-term in certain areas. This could make our solar service offerings less economical overall, make individual systems less economical, or reduce demand for our products, as well as damage our reputation to the extent energy generation from our products does not meet customer expectations. For more information regarding risks posed by meteorological conditions, see “— Sales and installation of solar energy systems depend heavily on suitable meteorological and environmental conditions. If meteorological or environmental conditions are unexpectedly unfavorable, the electricity production from our solar service offerings may be below our expectations, and our ability to timely deploy new systems may be adversely impacted.”

Our business has benefited from the declining cost of solar energy system and energy storage system components and may be harmed to the extent the cost of such components stabilizes or increases in the future.

Our business has benefited from the declining cost of solar energy system and energy storage system components, and to the extent such costs stabilize, decline at a slower rate or increase, our future growth rate may be negatively impacted. The declining cost of solar energy system and energy storage system components and the raw materials necessary to manufacture them has been a key driver in the price of solar energy systems and energy storage systems and customer adoption of solar energy. While historically solar energy system and energy storage system components and raw material prices have declined, the cost of these components and raw materials have recently increased and may continue to increase in the future, and such products’ availability could decrease, due to a variety of factors, including growth in the solar energy system and energy storage system industries and the resulting increase in demand for solar energy system and energy storage system components and the raw materials necessary to manufacture them, supply chain disruptions, tariff penalties, duties, and trade barriers, export regulations, regulatory or contractual limitations,

industry market requirements and industry standards, changes in technology, the loss of or changes in economic governmental incentives, inflation or other factors. An increase in the prices of solar energy system components and raw materials could slow our growth and cause our business and results of operations to suffer. See “— Increases in the cost or reduction in supply of solar energy system and energy storage system components due to tariffs or trade restrictions imposed by the U.S. government could have an adverse effect on our business, financial condition and results of operations.”

Risks Related to Operations

We may be unable to sustain our level of profitability in the future.

We may incur net losses as we increase our spending to finance the expansion of our operations, expand our installation, engineering, administrative, sales and marketing staffs, increase spending on our brand awareness and other sales and marketing initiatives, make significant investments to drive future growth in our business and implement internal systems and infrastructure to support our growth and operate as a publicly traded company. We do not know whether our revenue will grow rapidly enough to absorb these costs and our limited operating history makes it difficult to assess the extent of these expenses or their impact on our results of operations. Our ability to sustain profitability depends on a number of factors, including but not limited to:

•        growing our customer base;

•        reducing our operating costs by lowering our customer acquisition costs and optimizing our design and installation processes and supply chain logistics;

•        maintaining or further lowering our cost of capital;

•        reducing the cost of components for our solar service offerings;

•        growing and maintaining our sales network;

•        maintaining high levels of product quality, performance, and customer satisfaction; and

•        growing our direct-to-consumer business to scale.

Even if we do sustain profitability, we may be unable to achieve positive cash flows from operations in the future.

Our growth depends in part on the success of our relationships with third parties such as our equipment suppliers, subcontractors and dealers, including dealers who market to customers and bring the resulting solar contracts to us for fulfillment.

A key component of our growth strategy is to develop or expand our relationships with third parties, such as our equipment suppliers, subcontractors and dealers. A significant portion of our business depends on attracting and retaining new and existing sales dealers who market to customers and bring the resulting contracts to us for fulfillment. Negotiating relationships with subcontractors, dealers and other third parties, training such third parties, and monitoring them for compliance with our standards require significant time and resources and may present greater risks and challenges than expanding our direct sales and installation team. If we are unsuccessful in establishing or maintaining our relationships with these third parties, our ability to grow our business and address our market opportunity could be impaired. Even if we are able to establish and maintain these relationships, we may not be able to execute our goal of leveraging these relationships to meaningfully expand our business, brand recognition and customer base. This would limit our growth potential and our opportunities to generate significant additional revenue or cash flows.

Due to the limited number of suppliers in our industry, the acquisition of any of these suppliers by a competitor or any shortage, delay, price change, imposition of tariffs or duties or other limitation in our ability to obtain components or technologies we use could result in sales and installation delays, cancellations and loss of customers.

We purchase solar panels, inverters, energy storage systems and other system components and instruments from a limited number of suppliers, qualified and approved by our engineering and design teams, making us susceptible

to quality issues, shortages and price changes that may occur in the supply chain. There are a limited number of suppliers of solar energy system components, instruments and technologies, and our ability to obtain components or technologies we use could be affected by circumstances beyond our control, including:

•        Industry-wide shortages of key components and instruments, including batteries and inverters, in times of rapid industry growth.    The manufacturing infrastructure for some of these components has a long lead-time, requires significant capital investment and relies on the continued availability of key commodity materials, potentially resulting in an inability to meet demand for these components. The solar industry is currently experiencing rapid growth and, as a result, shortages of key components or instruments, including solar panels, may be more likely to occur, which in turn may result in price increases for such components. Even if industry-wide shortages do not occur, suppliers may decide to allocate key components or instruments with high demand or insufficient production capacity to more profitable customers, customers with long-term supply agreements or customers other than us. As a result, our ability to originate solar energy systems and energy storage systems may be reduced.

•        Natural disasters and other events beyond our control (such as earthquakes, wildfires, flooding, hurricanes, freezes, tsunamis, typhoons, volcanic eruptions, droughts, tornadoes, power outages or other natural disasters, the effects of climate change and related extreme weather, public health issues and pandemics, war, terrorism, government restrictions or limitations on trade, impediments to international shipping and geopolitical unrest and uncertainties).

•        Human rights and forced labor issues in foreign countries and the U.S. government’s response to them.    In particular, the withhold release order issued by U.S. Customs and Border Protection in June 2021 applicable to certain silica-based products manufactured in the Xinjiang Uyghur Autonomous Region (“XUAR”) of China, and any other allegations regarding forced labor in China and U.S. trade regulations to prohibit the importation of any goods derived from forced labor, could affect our operations. Further, the Uyghur Forced Labor Prevention Act (“UFLPA”) that President Biden signed into law on December 23, 2021, which took effect on June 21, 2022, has affected and may continue to affect our supply chain and operations. Intensive examinations, withhold release orders, and related governmental procedures have resulted in supply chain and operational delays throughout the industry. These and other similar trade restrictions that may be imposed in the future could cause delivery and installation delays and restrict the global supply of polysilicon and solar products. While we believe the items described above have contributed to price increases for components that we purchase, we believe that these increases to the cost of our components were also due to a combination of other factors, including general supply chain issues resulting from COVID-19, other supply chain constraints, increased demand for solar systems in the U.S. and Europe, rising inflation, and higher labor, material, and shipping costs. We do not have information that allows us to quantify the specific amount of price increases attributable to the tariffs and trade regulations described. For more information regarding UFLPA and risks related thereto, see “— Increases in the cost or reduction in supply of solar energy system and energy storage system components due to tariffs or trade restrictions imposed by the U.S. government could have an adverse effect on our business, financial condition and results of operations.”

•        Russia’s war on Ukraine.    We do not materially rely directly or indirectly on goods or services sourced in Russia, Ukraine or Belarus, or have any material business relationships, connections to, or assets in, Russia, Belarus, or Ukraine. While we believe Russia’s war on Ukraine has contributed to price increases for components that we purchase, we believe that the increases to the cost of our components were also due to a combination of other factors, including general supply chain issues resulting from COVID-19, other supply chain constraints, tariffs and trade regulations, increased demand for solar systems in the U.S. and Europe, U.S. tariffs, rising inflation, and higher labor, material, and shipping costs. We do not have information that allows us to quantify the specific amount of price increases attributable to Russia’s war on Ukraine.

•        Disruptions to global shipping.    Historically, we have relied on foreign suppliers and manufacturers for a number of solar energy system components, instruments and technologies that we purchase. Our success in the future may be dependent on our ability to import or transport such products from overseas vendors in a timely and cost-effective manner. We may rely heavily on third parties, including ocean carriers and truckers, both of which are experiencing disruptions, shortages and rate increases, in that process. The

global shipping industry has experienced and may continue to experience ocean shipping disruptions, trucking shortages, increased ocean shipping rates and increased trucking and fuel costs. There has been and may in the future be a shortage of shipping capacity from China and other parts of Asia, among other regions, and as a result, our receipt of imported products may be disrupted or delayed. The shipping industry has also experienced issues with port congestion and pandemic-related port closures and ship diversions. The global shipping industry also experienced unprecedented increases in shipping rates from the trans-Pacific and other ocean carriers due to various factors, including limited availability of shipping capacity. In 2020, 2021, and 2022, we experienced periods of temporary delay in obtaining supplies. We believe these delays reduced the number of installations in comparison to what we would have been able to install without the delays. In 2023, we did not experience any appreciable delays in supply. We may find it necessary to rely on an increasingly expensive spot market and other alternative sources to make up any shortfall in shipping needs.

•        The COVID-19 pandemic.    For more information, see “— The COVID-19 pandemic, including its variants, has had, and it, along with other future pandemics, could continue to have an adverse impact on our business, operations, and the markets and communities in which we operate.”

If we cannot obtain substitute materials or components on a timely basis or on acceptable terms, we could be prevented from installing our solar energy systems within the time frames required in our customer contracts. Any such delays could increase our overall costs, reduce our profit, delay the timing for solar energy systems to be placed in service and ultimately have a material adverse effect on our business, financial condition and results of operations.

We depend on a limited number of suppliers of solar energy system components and technologies to adequately meet demand for our solar energy systems. If we needed to identify alternative suppliers or to qualify alternative products on commercially reasonable terms, our ability to satisfy demand may be adversely affected.

Our primary supplier is Consolidated Electrical Distributors, Inc (d/b/a Greentech Renewables) (“Greentech”), from which we purchased approximately 98% of the equipment that we installed in 2023. If Greentech or one or more of our other suppliers we rely upon to meet anticipated demand (i) ceases or reduces production due to its financial condition, acquisition by a competitor or otherwise, (ii) is unable to increase production as industry demand increases, (iii) raises their prices to an extent that cannot be passed on to our customers without affecting demand or (iv) is otherwise unable to allocate sufficient production to us, it may be difficult to quickly identify alternative suppliers or to qualify alternative products on commercially reasonable terms. As a result, our ability to satisfy demand may be adversely affected.

Although we buy the majority of our equipment through Greentech, we believe that if our relationship with Greentech were terminated, we could readily obtain supplies from other distributors of the same or similar equipment, though in some locations replacement distributors may take some time to develop efficient logistics with respect to shipping equipment directly to job sites. This could result in additional costs and delays in acquiring and deploying our solar energy systems or energy storage systems.

Increased scrutiny of environmental, social, and governance (“ESG”) matters could have an adverse effect on our business, financial condition and results of operations and damage our reputation.

In recent years, companies across all industries are facing increasing scrutiny from a variety of stakeholders, including investor advocacy groups, proxy advisory firms, certain institutional investors and lenders, investment funds and other influential investors and rating agencies, related to their ESG and sustainability practices. If we do not adapt to or comply with investor or other stakeholder expectations and standards on ESG matters as they continue to evolve, or if we are perceived to have not responded appropriately or quickly enough to growing concern for ESG and sustainability issues, regardless of whether there is a regulatory or legal requirement to do so, we may suffer from reputational damage and our business, financial condition and/or stock price could be materially and adversely affected. In addition, organizations that provide information to investors on corporate governance and related matters have developed ratings processes for evaluating companies on their approach to ESG matters. Such ratings are used by some investors to inform their investment and voting decisions. Unfavorable ESG ratings could lead to increased negative investor sentiment toward us and our industry and to the diversion of investment to other industries, which could have a negative impact on our stock price and our access to and costs of capital.

We and our suppliers and subcontractors are subject to risks associated with construction, cost overruns, delays, customer cancellations, regulatory compliance, and other contingencies, any of which could have a material adverse effect on our business and results of operations.

We are a licensed contractor in certain communities that we service, and we are ultimately responsible as the contracting party for every solar energy system installation we provide. We may be liable, either directly or through our subcontractors, to customers for any damage we cause to them, their home, belongings or property during the installation of our systems. For example, we, either directly or through our subcontractors, frequently penetrate customers’ roofs during the installation process and may incur liability for the failure to adequately weatherproof such penetrations following the completion of construction. In addition, because the solar energy systems we or our subcontractors deploy are high voltage energy systems, we may incur liability for any failure to comply with electrical standards and manufacturer recommendations. Legal proceedings that are not resolved in our favor could potentially result in fines, public reprimand, probation, or the suspension or revocation of certain of our licenses.

Completing the sale and installation of a solar energy system requires many different steps including a site audit, completion of designs, permitting, installation, electrical sign-off and interconnection. Customers may cancel their customer agreement for a limited period, subject to certain conditions, and we have experienced increased customer cancellations in certain geographic markets during certain periods in our operating history. We or our dealers or subcontractors may face customer cancellations, delays or cost overruns, which may adversely affect our or our dealers’ or contactors’ ability to ramp up the volume of sales or installations in accordance with our plans. These cancellations, delays or overruns may be the result of a variety of factors, such as labor shortages or other labor issues, defects in materials and workmanship, adverse weather conditions, transportation constraints, construction change orders, site changes or roof conditions, geographic factors and other unforeseen difficulties, any of which could lead to increased cancellation rates, reputational harm and other adverse effects. For example, some customer orders are cancelled after a site visit if we determine that a customer needs to make repairs to or install a new roof, or that there is excessive shading on their property. If we continue to experience increased customer cancellations, our financial results may be materially and adversely affected.

In addition, the installation of solar energy systems and other energy-related products requiring building modifications are subject to oversight and regulation in accordance with national, state and local laws and ordinances relating to building, fire and electrical codes, safety, environmental protection, utility interconnection and metering, and related matters. We also rely on certain of our and our subcontractors’ employees to maintain professional licenses in many of the jurisdictions in which we operate, and our failure to employ properly licensed personnel could adversely affect our licensing status in those jurisdictions. It is difficult and costly to track the requirements of every individual authority having jurisdiction over our installations and to design solar energy systems to comply with these varying standards. Any new government regulations or utility policies pertaining to our systems may result in significant additional expenses to us and our customers and, as a result, could cause a significant reduction in demand for our solar service offerings.

As the demand for solar plus storage offerings grows, we anticipate facing additional operational challenges associated with the complexity of deploying storage solutions. For example, solar plus storage offerings tend to have longer cycle times due to factors such as lengthened permitting and inspection times and potential need of a main panel upgrade.

We have a variety of quality standards that we apply in the selection, supervision, and oversight of our third-party suppliers and subcontractors. However, because our suppliers and subcontractors are third parties, ultimately, we cannot guarantee that they will follow applicable laws and regulations, any standards we impose, or ethical business practices, such as fair wage practices and compliance with environmental, safety and other local laws, despite our efforts to hold them accountable to our standards. A lack of demonstrated compliance with contractual obligations, applicable laws and regulations or our standards could lead us to seek alternative suppliers or subcontractors, which could increase our costs and result in delayed delivery or installation of our products, product shortages or other disruptions of our operations. Violation of labor or other laws by our suppliers and subcontractors or the divergence of a supplier’s or subcontractor’s labor or other practices from those generally accepted as ethical in the United States or other markets in which we do business could also attract negative publicity for us and harm our business, brand and reputation in the market.

We use subcontractors to perform certain services, which makes us vulnerable to the extent we rely on them.

We rely on subcontractors to install some of the solar energy systems we sell, as well as install energy efficiency equipment such as hybrid electric water heaters and pool pumps and provide roofing and insulation services. We currently do not have long term agreements with our subcontractors. In addition, either the subcontractor or Zeo can terminate the relationship for convenience. If a subcontractor terminates their relationship with us or refuses to continue working with us on reasonable terms, and we cannot find a suitable replacement subcontractor on a timely basis, our business may be adversely affected.

Compliance with occupational safety and health requirements and best practices can be costly, and noncompliance with such requirements may result in potentially significant penalties, operational delays and adverse publicity.

The installation and ongoing operations and maintenance of solar energy systems and energy storage systems requires our employees or those of third-party contractors to work with complicated and potentially dangerous electrical systems and/or at potentially dangerous heights. The evaluation and modification of buildings as part of the installation process requires these individuals to work in locations that may contain potentially dangerous levels of asbestos, lead, mold or other materials known or believed to be hazardous to human health. We also maintain large fleets of vehicles that these employees use in the course of their work. There is substantial risk of serious illness, injury, or death if proper safety procedures are not followed. Our operations are subject to regulation under the U.S. Occupational Safety and Health Act (“OSHA”), Department of Transportation regulations, and equivalent state laws. Changes to such regulatory requirements, or stricter interpretation or enforcement of existing laws or regulations, could result in increased costs. If we fail to comply with applicable workplace safety and health regulations, even if no work-related serious illness, injury, or death occurs, we may be subject to civil or criminal enforcement and be required to pay substantial penalties, incur significant capital expenditures, or suspend or limit operations. Any accidents, citations, violations, illnesses, injuries or failure to comply with industry best practices may subject us to adverse publicity, damage our reputation and competitive position and adversely affect our business. Because individuals hired by us or on our behalf to perform installation and ongoing operations and maintenance of our solar energy systems and energy storage systems, including our third-party contractors, are compensated on a per project basis, they are incentivized to work more quickly than installers compensated on an hourly basis. While we have not experienced a high level of injuries to date, this incentive structure may result in higher injury rates than others in the industry and could accordingly expose us to increased liability.

If we fail to manage our recent and future growth effectively, we may be unable to execute our business plan, maintain high levels of customer service, or adequately address competitive challenges.

We have experienced significant growth in recent periods and we intend to continue to expand our business within existing markets and in a number of new locations in the future. This growth has placed, and any future growth may continue to place, a significant strain on our management, operational and financial infrastructure. In particular, we have been in the past, and may in the future, be required to expand, train and manage our growing employee base and subcontractors. Our management will also be required to maintain and expand our relationships with customers, suppliers, and other third parties and attract new customers and suppliers, as well as to manage multiple geographic locations.

In addition, if customer growth results in a backlog of installation projects, our installation capacity may be outpaced by the growth of such backlog. An increase in backlog creates higher costs incurred in the period relative to completed installations. If we fail to appropriately manage our backlog in relation to the rate at which we install, it could adversely affect our financial performance and hinder our ability to compete effectively.

Our current and planned operations, personnel, systems and procedures might also be inadequate to support our future growth and may require us to make additional unanticipated investment in our infrastructure, including additional costs for the expansion of our employee base and our subcontractors as well as marketing and branding costs. Our success and ability to further scale our business will depend, in part, on our ability to manage these changes in a cost-effective and efficient manner. If we cannot manage our growth, we may be unable to take advantage of market opportunities, execute our business strategies or respond to competitive pressures. This could also result in declines in quality or customer satisfaction, increased costs, difficulties in introducing new solar service offerings or other operational difficulties. Any failure to effectively manage growth could adversely impact our business, operating results, financial condition and reputation.

The execution of our growth strategy is dependent upon the continued availability of third-party financing arrangements for our customers’ purchases and is affected by general economic conditions and other factors.

Our growth strategy depends on third-party financing arrangements for our customers’ purchases. Most purchasers of our systems have entered into such third-party arrangements to finance their systems over an extended period of time.

Credit markets are unpredictable, and if they become more challenging, customers may be unable or unwilling to finance the cost of our products or the parties that have historically provided this financing may cease to do so, or only do so on terms that are substantially less favorable for our customers, either of which could materially and adversely affect our revenue and growth. In addition, a rise in interest rates would likely increase our customers’ cost of financing our products and could reduce their profits and expected returns on investment in our products. The general reduction in available credit to would-be borrowers or lessees, worldwide economic uncertainty, and the condition of worldwide housing markets could delay or reduce our sales of products to new homebuilders and authorized resellers.

The COVID-19 pandemic, including its variants, has had, and it, along with other future pandemics, could continue to have an adverse impact on our business, operations, and the markets and communities in which we operate.

Our business and financial condition have been, and could continue to be, affected by the COVID-19 pandemic, including its variants. The COVID-19 pandemic has had an unprecedented impact on the U.S. economy and has impacted our business. The effects of COVID-19, such as the widespread growth in infections, travel restrictions, quarantines, return-to-work restrictions, government regulations, supply chain disruptions, workforce shortages, and site closures have impacted and may continue to impact our ability to staff sales and operations centers and install and maintain solar energy systems in the field, as well as direct-to-home sales activities. The rise and resurgence of increasingly infectious variants, despite efforts to combat the virus with vaccinations, has presented additional challenges and unpredictability that have, and may continue to have, resulted in workforce constraints, delays, and additional costs, particularly in regions experiencing significant outbreaks.

The COVID-19 pandemic has also led to significant volatility in global financial markets, which could negatively affect our cost of and access to capital and could have an adverse impact on customer demand and the financial health and credit risk associated with our customers. Future disruptions or instability in capital markets could also negatively impact our ability to raise capital from third parties, such as tax equity partners, to grow our business. In addition, significant inflation, a recession or a market correction resulting from the impacts of the COVID-19 pandemic has and could continue to adversely affect our business. The full economic impact of the pandemic is still not known.

COVID-19 has caused disruptions to the supply chain across the global economy, including within the solar industry. Certain suppliers have experienced, and may continue to experience, delays related to a variety of factors, including logistical delays and component shortages from upstream vendors. In 2020, 2021, and 2022, we experienced periods of temporary delay in obtaining supplies. We believe these delays reduced the number of installations in comparison to what we would have been able to install without the delays. In 2023, we did not experience any appreciable delays in supply. We continue to monitor the situation and are working closely with our subcontractors and suppliers to develop contingency plans for potential operations and supply chain interruptions.

Additionally, if the impacts of the COVID-19 pandemic worsen, or another pandemic were to spread, the supply and pricing of our inverters and other goods and therefore our ability to sell new solar energy systems could be adversely affected. The extent of the impact of the COVID-19 pandemic or another pandemic on our business and operations will depend on, among other factors, the duration and severity of the outbreak, travel restrictions and business closures imposed in China or other countries and their ability to recover from such restrictions when they are lifted, the ability of our suppliers to increase their production of goods in jurisdictions other than China, our ability to contract for supply from other sources on acceptable terms and the willingness of our lenders to permit us to switch suppliers. While we believe that COVID-19 has contributed to price increases for components that we purchase, we believe that the increases to the cost of our components were also due to a combination of other factors, including supply chain constraints, Russia’s war on Ukraine, increased demand for solar systems in the U.S. and Europe, tariffs and trade regulations, rising inflation, and higher labor, material, and shipping costs. We do not have information that allows us to quantify the specific amount of price increases attributable to COVID-19.

The ultimate impact of the COVID-19 pandemic or other future pandemics is highly uncertain, beyond our control, dependent on future developments that cannot be accurately predicted, and subject to change. We will continue to monitor developments affecting our workforce, our customers, and our business operations generally and will take additional actions that we determine are necessary in order to mitigate the impacts; however, any steps we take may be inadequate and, as a result, our business may be harmed.

The cost of maintenance or repair of solar energy systems or energy storage systems throughout the period for which we have offered warranties may be higher than projected today and adversely affect our financial performance and valuation.

Prior to 2023, we generally provided a 25-year workmanship warranty and 25-year roof penetration warranty to customers. Beginning in 2023, we generally provide a 10-year workmanship warranty and a roof penetration warranty of at least five and up to twenty-five years. For the first two years of the workmanship warranty, we cover all costs to repair failures covered by the warranty. After two years, the customer is responsible for certain “truck roll” or service fees, but we otherwise cover the costs of repair. For leases, we provide a twenty five-year limited workmanship warranty and cover all costs for repairs performed under such warranty.

If a solar system or energy storage system fails or malfunctions during the period for which we have offered our workmanship warranty and the failure is covered by such warranty, or if roof damage is covered by the roof penetration warranty, we will incur expenses for maintenance or repair. While our subcontractors provide warranties as to their workmanship, in the event such warranty providers file for bankruptcy, cease operations or otherwise become unable or unwilling to fulfill their warranty obligations, we may not be adequately protected by such warranty obligations. Even if such warranty providers fulfill their obligations, the warranty obligations may not be sufficient to protect us against all of our losses.

Furthermore, it is difficult to predict how future environmental regulations may affect the costs associated with the repair, removal, disposal or recycling of our solar energy systems. This could materially impair our future operating results.

Problems with product quality or performance may lower the residual value of our solar energy systems and may damage our market reputation and cause our financial results to decline.

Because of our limited operating history and the length of the term of our warranties, we have been required to make assumptions and apply judgments regarding a number of factors, including our anticipated rate of warranty claims and the durability, performance and reliability of our solar energy systems. Any widespread product failures or operating deficiencies may damage our market reputation and adversely impact our financial results.

Warranties provided by the manufacturers of equipment we sell or service may be limited by the ability of a supplier and manufacturer to satisfy its warranty or performance obligations or by the expiration of applicable time or liability limits, which could reduce or void the warranty protections of our customers and increase costs to customers for the systems we offer.

Manufacturers of the equipment we sell currently provide a manufacturer’s warranty for 25 years. If there is a covered failure of equipment, the manufacturer will pay for replacement or repair. These warranties are subject to liability and other limits. If a customer seeks warranty protection and a warranty provider is unable or unwilling to perform its warranty obligations, whether as a result of its financial condition or otherwise, or if the term of the warranty obligation has expired or a liability limit has been reached, there may be a reduction or loss of protection for the affected assets and an increase in costs to the customer. Any widespread product failures or operating deficiencies may damage our market reputation and adversely impact our financial results.

Product liability claims against us or accidents could result in adverse publicity and potentially significant monetary damages.

It is possible the solar energy systems, energy storage systems or other current or anticipated products or systems we sell could injure our customers or other third parties or those systems or products could cause property damage as a result of product malfunctions, defects, improper installation, fire or other causes. We rely on third-party manufacturing warranties and our general liability insurance to cover product liability claims and have not obtained separate product liability insurance. Our solar energy systems, energy storage systems and other products or their

components could be subject to recalls either due to production defects or malfunctions. Any product liability claim we face could be expensive to defend and may divert management’s attention. The successful assertion of product liability claims against us could result in potentially significant monetary damages, potential increases in insurance expenses, penalties or fines, subject us to adverse publicity, damage our reputation and competitive position and adversely affect sales of solar energy systems or energy storage systems. In addition, product liability claims, injuries, defects or other problems experienced by other companies in the solar industry could lead to unfavorable market conditions to the industry as a whole and may have an adverse effect on our ability to expand our portfolio of solar energy systems and energy storage systems, thus affecting our business, financial condition and results of operations.

Technical and regulatory limitations regarding the interconnection of solar energy systems to the electrical grid may significantly delay interconnections and customer in-service dates, harming our growth rate and customer satisfaction.

Technical and regulatory limitations regarding the interconnection of solar energy systems to the electrical grid may curb or slow our growth in key markets. Utilities throughout the country follow different rules and regulations regarding interconnection and regulators or utilities have or could cap or limit the amount of solar energy that can be interconnected to the grid. Our solar energy systems generally do not provide power to a customer’s site until they are interconnected to the grid.

With regard to interconnection limits, the Federal Energy Regulatory Commission (“FERC”), in promulgating the first form of small generator interconnection procedures, recommended limiting customer-sited intermittent generation resources, such as our solar energy systems, to a certain percentage of peak load on a given electrical feeder circuit. Similar limits have been adopted by many states as a de facto standard and could constrain our ability to market to customers in certain geographic areas where the concentration of solar installations exceeds this limit.

Furthermore, in certain areas, we benefit from policies that allow for expedited or simplified procedures related to connecting solar energy systems and energy storage systems to the electrical grid. We also are required to obtain interconnection permission for each solar energy system from the local utility. In many states and territories, by statute, regulations or administrative order, there are standardized procedures for interconnecting distributed solar energy systems and related energy storage systems to the electric utility’s local distribution system. However, approval from the local utility could be delayed as a result of a backlog of requests for interconnection or the local utility could seek to limit the number of customer interconnections or the amount of solar energy on the grid. If expedited or simplified interconnection procedures are changed or cease to be available, if interconnection approvals from the local utility are delayed or if the local utility seeks to limit interconnections, this could decrease the attractiveness of new solar energy systems and energy storage systems to distributed solar power companies, including us, and the attractiveness of solar energy systems and energy storage systems to customers. Delays in interconnections could also harm our growth rate and customer satisfaction scores. Such limitations or delays could also adversely impact our access to capital and reduce our willingness to pursue solar energy systems and energy storage systems due to higher operating costs. Such limitations would negatively impact our business, results of operations, future growth and cash flows.

As adoption of solar distributed generation rises, along with the increased operation of utility-scale solar generation, the amount of solar energy being contributed to the electrical grid may surpass the capacity anticipated to be needed to meet aggregate demand. If solar generation resources reach a level capable of producing an over-generation situation, some existing solar generation resources may have to be curtailed to maintain operation of the electrical grid. In the event such an over-generation situation were to occur, this could also result in a prohibition on the installation of new solar generation resources. The adverse effects of such a curtailment or prohibition without compensation could adversely impact our business, results of operations, future growth and cash flows.

Our headquarters and other facilities, the facilities of certain subcontractors and suppliers, and our customers are concentrated in certain regions, putting us at risk of region-specific disruptions, including hurricanes or other extreme weather events.

For the twelve months ended December 31, 2023, approximately 92% of our sales were made in Florida. This concentration of our customer base and operational infrastructure could lead to our business and results of operations being particularly susceptible to adverse economic, regulatory, political, weather and other conditions in this market and in other markets that may become similarly concentrated.

Our headquarters are also located in Florida, and we have offices and operations in Texas and Arkansas, operations in Missouri, and sales, marketing and executive offices in Utah. Any significant epidemic, hurricane, earthquake, flood, fire, or other natural disaster in these areas or in countries where our suppliers or the manufacturers of the products we sell are located could materially disrupt our operations, result in damage or destruction of all or a portion of our facilities or result in our experiencing a significant delay in delivery, or substantial shortage, of our products and services.

We may not have adequate insurance, including business interruption insurance, to compensate us for losses that may occur from any such significant events. A significant natural disaster such as a hurricane, a public health crisis such as a pandemic, or civil unrest could have a material adverse impact on our business, results of operations and financial condition. In addition, acts of terrorism or malicious computer viruses could cause disruptions in our or our subcontractors’ and suppliers’ businesses or the economy as a whole. To the extent that these disruptions result in delays or cancellations of installations or the deployment of our solar service offerings, our business, results of operations and financial condition would be adversely affected.

Expansion into new sales channels could be costly and time-consuming. As we enter new channels, we could be at a disadvantage relative to other companies who have more history in these spaces.

If we expand into new sales channels, such as direct-to-home, homebuilder, retail, and e-commerce channels, or adapt to a remote selling model, we may incur significant costs. In addition, we may not initially or ever be successful in utilizing these new channels. Furthermore, we may not be able to compete successfully with companies with a historical presence in such channels, and we may not realize the anticipated benefits of entering such channels, including efficiently increasing our customer base and ultimately reducing costs. Entering new channels also poses the risk of conflicts between sales channels. If we are unable to successfully compete in new channels, our operating results and growth prospects could be adversely affected.

Obtaining a sales contract with a potential customer does not guarantee that the potential customer will not decide to cancel or that we will not need to cancel due to a failed inspection, which could cause us to generate no revenue despite incurring costs and adversely affect our results of operations.

Even after we secure a sales contract with a potential customer, we (either directly or through our subcontractors) must perform an inspection to ensure the home, including the rooftop, meets our standards and specifications. If the inspection finds repairs to the rooftop are required in order to satisfy our standards and specifications to install the solar energy system, and a potential customer does not want to make such required repairs, we would lose that anticipated sale. In addition, per the terms of our customer agreements, a customer maintains the ability to cancel for a limited time after execution of the agreement, and in some other circumstances subject to specified conditions. An accumulation of delays or cancellations of anticipated sales could materially and adversely affect our financial results, as we may have incurred sales-related, design-related, and other expenses and generated no revenue.

We may not realize the anticipated benefits of past or future investments, strategic transactions, or acquisitions, and integration of these acquisitions may disrupt our business and management.

We have in the past and may in the future acquire one or more companies, project pipelines, projects, solar renewable energy credits (“SRECs”), products, or technologies or enter into joint ventures or other strategic transactions. We may not realize the anticipated benefits of past or future investments, strategic transactions, or acquisitions, and these transactions involve numerous risks that are not within our control. These risks include the following, among others:

•        failure to satisfy the required conditions and otherwise complete a planned acquisition, joint venture or other strategic transaction on a timely basis or at all;

•        legal or regulatory proceedings, if any, relating to a planned acquisition, joint venture or other strategic transaction and the outcome of such legal proceedings;

•        difficulty in assimilating the operations, systems, and personnel of the acquired company;

•        difficulty in effectively integrating the acquired technologies or products with our current products and technologies;

•        difficulty in maintaining controls, procedures and policies during the transition and integration;

•        disruption of our ongoing business and distraction of our management and employees from other opportunities and challenges due to integration issues;

•        difficulty integrating the acquired company’s accounting, management information and other administrative systems;

•        inability to retain key technical and managerial personnel of the acquired business;

•        inability to retain key customers, vendors and other business partners of the acquired business;

•        inability to achieve the financial and strategic goals for the acquired and combined businesses;

•        incurring acquisition-related costs or amortization costs for acquired intangible assets that could impact our results of operations;

•        significant post-acquisition investments that may lower the actual benefits realized through the acquisition;

•        potential failure of the due diligence processes to identify significant issues with product quality, legal, and financial liabilities, among other things;

•        moderating and anticipating the impacts of inherent or emerging seasonality in acquired customer agreements;

•        potential inability to assert that internal controls over financial reporting are effective; and

•        potential inability to obtain, or obtain in a timely manner, approvals from governmental authorities, which could delay or prevent such acquisitions.

Our failure to address these risks, or other problems encountered in connection with our past or future investments, strategic transactions, or acquisitions, could cause us to fail to realize the anticipated benefits of these acquisitions or investments, cause us to incur unanticipated liabilities, and harm our business generally. Future acquisitions could also result in dilutive issuances of our equity securities, the incurrence of debt, contingent liabilities, amortization expenses, incremental expenses or the write-off of goodwill, any of which could harm our financial condition or results of operations.

Mergers and acquisitions are inherently risky, may not produce the anticipated benefits and could adversely affect our business, financial condition or results of operations.

Disruptions to solar production metering and energy storage solutions could negatively impact customer experiences, which could damage our market reputation and adversely impact our financial results.

Our customers’ ability to monitor solar energy production for various purposes depends on the operation of the metering solution. For example, some meters and/or inverters operate on either the 3G or 4G cellular data networks, which are expected to sunset in the near future, and newer technologies we use today may also become obsolete. Disruptions to solar production metering and energy storage solutions could negatively impact customer experiences, which could damage our market reputation and adversely impact our financial results.

Our business may be harmed if we fail to properly protect our intellectual property, or if we are required to defend against claims or indemnify others against claims that we infringe on the intellectual property rights of third parties.

We believe that the success of our business depends in part on our proprietary information, processes and know-how. We rely on copyright and trade secret protections to secure our intellectual property. We also typically require employees, consultants, and third parties, such as our vendors and customers, with access to our proprietary information to execute confidentiality agreements. Although we may incur substantial costs in protecting our intellectual property, we cannot be certain that we have adequately protected or will be able to adequately protect it because, among other reasons:

•        others may not be deterred from misappropriating our intellectual property despite the existence of laws or contracts prohibiting such misappropriation and information security measures designed to deter or prevent misappropriation of our intellectual property;

•        we have not obtained intellectual property assignment agreements from our founders or from a contract developer of certain software that we intend to use;

•        foreign intellectual property laws and associated foreign legal enforcement regimes may not adequately protect our intellectual property rights; and

•        policing unauthorized use of our intellectual property may be difficult, expensive, and time-consuming, the remedy obtained may be inadequate to restore protection of our intellectual property, and moreover, we may be unable to determine the extent of any unauthorized use.

In addition, we cannot be certain that our intellectual property provides us with a competitive advantage. Despite our precautions, it may be possible for third parties to develop similar intellectual property independently or obtain and use our intellectual property without our consent. Reverse engineering, unauthorized copying, or other misappropriation of our intellectual property could enable third parties to benefit from our intellectual property without compensating us for doing so. Unauthorized use of our intellectual property by third parties, any other inability to adequately protect our proprietary rights, and the expenses incurred in protecting our intellectual property rights may adversely affect our business.

In the future, we may also be required to defend against claims that we have infringed on the intellectual property of third parties, and we cannot be certain that we will prevail in any intellectual property dispute. Any future litigation required to enforce our intellectual property, to protect our trade secrets or know-how or to defend us or indemnify others against claimed infringement of the rights of third parties could harm our business, financial condition, and results of operations.

We use “open source” software components in our solutions as well as other licensed software, which may require that we release the source code of certain software subject to open source licenses or subject us to possible litigation or other actions that could adversely affect our business.

We utilize software that is licensed under so-called “open source,” “free” or other similar licenses, or that contain components that are licensed in such manner. Our use of open source software may entail different or greater risks than use of third-party commercial software. Open source licensors sometimes do not provide warranties or other contractual protections regarding infringement claims or the quality of the code, and open source software is sometimes made available to the general public on an “as-is” basis under the terms of a non-negotiable license. In addition, if we combine our proprietary software with open source software in a certain manner, we could, under certain open source licenses, be required to release the source code of our proprietary software to the public. We do not believe we have combined any of our proprietary software with open source software in such a manner, but if that were to occur this would allow our competitors to create similar offerings with lower development effort and time.

We may also face claims alleging noncompliance with open source license terms or other license terms, or infringement or misappropriation of proprietary software. These claims could result in litigation, require us to purchase a costly license or require us to devote additional research and development resources to change our software, any of which would have a negative effect on our business and results of operations. Few courts have interpreted open source licenses and these licenses could be construed in a way that could impose unanticipated conditions or restrictions on our ability to use our proprietary software. We cannot guarantee that we have incorporated or will incorporate open source or other software in our software in a manner that will not subject us to liability or require us to release the source code of our proprietary software to the public.

Any security breach, unauthorized access or disclosure, or theft of data, including personal information, we, our third party service providers, and suppliers gather, store, transmit, and use, or other hacking, cyber-attack, phishing attack, and unauthorized intrusions into or through our systems or those of our third party service providers, could harm our reputation, subject us to claims, litigation, financial harm, and have an adverse impact on our business.

In the ordinary course of business, we, our third party providers upon which we rely and our suppliers receive, store, transmit and use data, including the personal information of customers, such as names, addresses, email addresses, credit information and other housing and energy use information, as well as the personal information of our employees. Unauthorized disclosure of such personal information, whether through a breach of our or our third party service providers’ and suppliers’ systems by an unauthorized party, including, but not limited to hackers, threat actors, sophisticated nation-states, nation-state-supported actors, personnel theft or misuse of information or otherwise, could

harm our business. In addition, we, our third party service providers upon which we rely and our suppliers may be subject to a variety of evolving threats, such as computer malware (including as a result of advanced persistent threat intrusions), ransomware, malicious code (such as viruses or worms), social engineering (including spear phishing and smishing attacks), telecommunications failures, natural disasters and extreme weather events, general hacking and other similar threats. Cybersecurity incidents have become more prevalent. As of the date of this prospectus, we have not experienced a material cybersecurity incident. However, cybersecurity incidents could occur on our systems and those of our third parties in the future. Our team members who work remotely pose increased risks to our information technology systems and data, because many of them utilize less secure network connections outside our premises.

Inadvertent disclosure of confidential data, such as personal information, or unauthorized access to this type of data in our possession by a third party, could result in future claims or litigation arising from damages suffered by those affected, government enforcement actions (for example, investigations, fines, penalties, audits and inspections), additional reporting requirements and/or oversight, indemnification obligations, reputational harm, interruptions in our operations, financial loss and other similar harms. In addition, we could incur significant costs in complying with the multitude of federal, state and local laws, and applicable independent security control frameworks, regarding the unauthorized disclosure of personal information. Although to our knowledge we have not experienced a material information security breach, we cannot assure you that the systems and processes we have to prevent or detect security breaches and protect the confidential information we receive, store, transmit and use, will provide absolute security. Finally, any perceived or actual unauthorized disclosure of such information, unauthorized intrusion or other cyberthreat could harm our reputation, substantially impair our ability to attract and retain customers, interrupt our operations and have an adverse impact on our business.

Our contracts may not contain limitations of liability, and even where they do, there can be no assurance that limitations of liability in our contracts are sufficient to protect us from liabilities, damages or claims related to our data privacy and security obligations.

Terrorist attacks or cyberattacks against centralized utilities could adversely affect our business.

Assets owned by utilities such as substations and related infrastructure have been physically attacked in the past and will likely be attacked in the future. These facilities are often protected by limited security measures, such as perimeter fencing. Any such attacks may result in interruption to electricity flowing on the grid and consequently interrupt service to our solar energy systems not combined with an energy storage system, which could adversely affect our operations. Furthermore, cyberattacks, whether by individuals or nation states, against utility companies could severely disrupt their business operations and result in loss of service to customers, which would adversely affect our operations.

We may be subject to information technology system failures or network disruptions that could damage our business operations, financial conditions or reputation.

We may be subject to information technology system failures and network disruptions. These may be caused by natural disasters, accidents, power disruptions, telecommunications failures, acts of terrorism or war, computer viruses, physical or electronic break-ins, or similar events or disruptions. System redundancy may be ineffective or inadequate, and our disaster recovery planning may not be sufficient for all eventualities. Such failures or disruptions could result in delayed or cancelled orders. System failures and disruptions could also impede the manufacturing and shipping of products, delivery of online services, transactions processing and financial reporting. Such system failures or network disruptions could damage our business operations, financial conditions or reputation.

Damage to our brand and reputation or failure to expand our brand would harm our business and results of operations.

We depend significantly on our brand and reputation for high-quality solar service offerings, engineering and customer service to attract customers, contractors and dealers, and grow our business. If we fail to continue to deliver our solar service offerings within the planned timelines, if our solar service offerings do not perform as anticipated or if we damage any customers’ properties or cancel projects, our brand and reputation could be significantly impaired. We also depend greatly on referrals from customers for our growth. Therefore, our inability to meet or exceed customers’

expectations would harm our reputation and growth through referrals. We have at times focused particular attention on expeditiously growing our direct sales force and our contractors, leading us in some instances to hire personnel or contractors who we may later determine do not fit our company culture and standards.

Given the sheer volume of interactions our sales force, dealers and contractors have with customers and potential customers, it is also unavoidable that some interactions will be perceived by customers and potential customers as less than satisfactory and result in complaints. If we cannot manage our hiring and training processes to limit potential issues and maintain appropriate customer service levels, our brand and reputation may be harmed and our ability to grow our business would suffer. In addition, if we were unable to achieve a similar level of brand recognition as our competitors, some of which may have a broader brand footprint, more resources and longer operational history, we could lose recognition in the marketplace among prospective customers, suppliers and subcontractors, which could affect our growth and financial performance. Our growth strategy involves marketing and branding initiatives that will involve incurring significant expenses in advance of corresponding revenue. We cannot assure you that such marketing and branding expenses will result in the successful expansion of our brand recognition or increase our revenue. We are also subject to marketing and advertising regulations in various jurisdictions, and overly restrictive conditions on our marketing and advertising activities may inhibit the sales of the affected products.

The loss of one or more members of our senior management or key personnel may adversely affect our operations.

We depend on our experienced management team, and the loss of one or more key executives could have a negative impact on our business. With any change in leadership, there is a risk to organizational effectiveness and employee retention as well as the potential for disruption to our business. We may be unable to replace key members of our management team and key personnel in the event we lose their services. Integrating new personnel into our management team could prove disruptive to our operations, require substantial resources and management attention and ultimately prove unsuccessful. An inability to attract and retain sufficient managerial personnel who have critical industry experience and relationships could limit or delay our strategic efforts, which could have a material adverse effect on our business, financial condition and results of operations.

A failure to hire and retain a sufficient number of employees and service providers in key functions would constrain our growth and our ability to timely complete customers’ projects and successfully manage customer accounts.

To support our growth, we need to hire, train, deploy, manage and retain a substantial number of skilled employees, engineers, design techs, installers, electricians, operations and sales managers and sales personnel.

Competition for qualified personnel in our industry is increasing, particularly for skilled personnel involved in the installation of solar energy systems. We have in the past been, and may in the future be, unable to attract or retain qualified and skilled installation personnel or installation companies to be our subcontractors, which would have an adverse effect on our business. We and our subcontractors also compete with the homebuilding and construction industries for skilled labor. As these industries grow and seek to hire additional workers, our cost of labor may increase. The unionization of the industry’s labor force could also increase our labor costs. Shortages of skilled labor could significantly delay a project or otherwise increase our costs. Because our profit on a particular installation is based in part on assumptions as to the cost of such project, cost overruns, delays or other execution issues may cause us to not achieve our expected margins or cover our costs for that project. Further, we need to continue to expand upon the training of our customer service team to provide high-end account management and service to customers before, during and following the point of installation of our solar energy systems. Identifying and recruiting qualified personnel and training them requires significant time, expense and attention. It can take several months before a new customer service team member is fully trained and productive at the standards that we have established. If we are unable to hire, develop and retain talented technical and customer service personnel, we may not be able to realize the expected benefits of this investment or grow our business.

In addition, to support the growth and success of our direct-to-consumer channel, we need to recruit, retain and motivate a large number of sales personnel on a continuing basis. We compete with many other companies for qualified sales personnel, and it could take many months before a new salesperson is fully trained on our solar service offerings. If we are unable to hire, develop and retain qualified sales personnel or if they are unable to achieve desired productivity levels, we may not be able to compete effectively.

If we or our subcontractors cannot meet our hiring, retention and efficiency goals, we may be unable to complete customers’ projects on time or manage customer accounts in an acceptable manner or at all. Any significant failures in this regard would materially impair our growth, reputation, business and financial results. If we are required to pay higher compensation than we anticipate, these greater expenses may also adversely impact our financial results and the growth of our business.

Regulators may limit the type of electricians qualified to install and service our solar and battery systems, or introduce other requirements on our installation staff, which may result in workforce shortages, operational delays, and increased costs.

Regulators may limit the type of electricians qualified to install and service our solar and battery systems, such as requiring that electricians installing such systems have a certain license, or introduce other requirements that would apply to our installation staff. While our workforce includes workers licensed to install and service our solar and battery systems, if we are unable to hire, develop and retain sufficient certified electricians, we may face operational delays and increased costs. In addition, our growth may be significantly constrained, which would negatively impact our operating results.

We have previously been subject to, and we may in the future be subject to, regulatory inquiries and litigation, all of which are costly, distracting to our core business and could result in an unfavorable outcome, or a material adverse effect on our business, financial condition, results of operations, or the trading price of our securities.

We have previously been subject to regulatory inquiries and litigation, and in the future, we may be involved in legal proceedings and receive inquiries from government and regulatory agencies from time to time. In the event that we are involved in significant disputes or are the subject of a formal action by a regulatory agency, we could be exposed to costly and time-consuming legal proceedings that could result in any number of outcomes. Although outcomes of such actions vary, any current or future claims or regulatory actions initiated by or against us, whether successful or not, could result in significant costs, costly damage awards or settlement amounts, injunctive relief, increased costs of business, fines or orders to change certain business practices, significant dedication of management time or diversion of significant operational resources, or otherwise harm our business.

If we are not successful in any legal proceedings and litigation, we may be required to pay significant monetary damages, which could hurt our results of operations. Lawsuits are time-consuming and expensive to resolve and divert management’s time and attention. Although we carry general liability insurance, our insurance may not cover potential claims or may not be adequate to indemnify us for all liability that may be imposed. We cannot predict how the courts will rule in any potential lawsuit against us. Decisions in favor of parties that bring lawsuits against us could subject us to significant liability for damages, adversely affect our results of operations and harm our reputation.

If we are unsuccessful in selling new services and products, our business, financial condition and results of operations could be adversely affected.

In the future, we may offer new products or services. There is a risk that such products or services may not work as intended, or that the marketing of the products or services may not be as successful as anticipated. The sale of new products and services generally requires substantial investment. We intend to continue to make substantial investments in new products and services, and it is possible that we may not acquire new products or product enhancements that compete effectively within our target markets or differentiate our products based on functionality, performance or cost, and thus our new products may not result in meaningful revenue. In addition, any delays in releasing new or enhanced products or services could cause us to lose revenue opportunities and potential customers. Any technical flaws in product releases could diminish the innovative impact of our products and have a negative effect on customer adoption and our reputation. If we fail to introduce new products or services that meet the demands of our customers or target markets or do not achieve market acceptance, or if we fail to penetrate new markets, our business, financial conditions and results of operations could be adversely affected.

Our operating results and our ability to grow may fluctuate on a seasonal basis and from quarter to quarter and year to year, which could make our future performance difficult to predict and could cause our operating results for a particular period to fall below expectations.

Our quarterly and annual operating results and our ability to grow are difficult to predict and may fluctuate significantly in the future. Historically, our sales volume has been highest during late spring, summer, and early fall. During this time, consumers in many locations see greater energy needs due to operating air conditioning systems and warm-weather appliances such as swimming pool pumps. Our door-to-door sales efforts are also aided during these months by increased daylight hours, and we have more sales personnel working during these months. We typically have largely or entirely scaled down our sales efforts during the late fall, winter and early spring. Snow, cold weather or other inclement weather can delay our installation of products and services.

We have experienced seasonal and quarterly fluctuations in the past and expect to experience such fluctuations in the future. In addition to the other risks described in this “Risk Factors” section, the following factors could cause our operating results to fluctuate:

•        expiration or initiation of any governmental rebates or incentives;

•        significant fluctuations in customer demand for our solar energy services, solar energy systems and energy storage systems;

•        our subcontractors’ ability to complete installations in a timely manner;

•        our and our subcontractors’ ability to gain interconnection permission for an installed solar energy system from the relevant utility;

•        the availability, terms and costs of suitable financing;

•        our ability to continue to expand our operations and the amount and timing of expenditures related to this expansion;

•        announcements by us or our competitors of significant acquisitions, strategic partnerships, joint ventures or capital-raising activities or commitments;

•        changes in our pricing policies or terms or those of our competitors, including electric utilities;

•        actual or anticipated developments in our competitors’ businesses, technology or the competitive landscape; and

•        natural disasters or other weather or meteorological conditions.

For these or other reasons, the results of any prior quarterly or annual periods should not be relied upon as indications of our future performance.

We may be unable to generate sufficient cash flows or obtain access to external financing necessary to fund our operations and make adequate capital investments as planned due to the general economic environment, cost inflation, and/or the market pressure driving down the average selling prices of our products and services, among other factors.

To acquire new products, support future growth, achieve operating efficiencies and maintain product quality, we may need to make significant capital investments in product and process technology as well as enhancing our digital capabilities. The delayed disposition of such projects, or the inability to realize the full anticipated value of such projects on disposition, could have a negative impact on our liquidity.

Certain municipalities where we install systems also require performance bonds in cash, issued by an insurance company or bonding agency, or bank guarantees or letters of credit issued by financial institutions, which are returned to us upon satisfaction of contractual requirements.

We manage our working capital requirements and fund our committed capital expenditures with our current cash and cash equivalents and cash generated from operations. If our capital resources are insufficient to satisfy our liquidity requirements, we may seek to sell additional equity investments or debt securities or obtain debt financing. Market conditions, however, could limit our ability to raise capital by issuing new equity or debt securities on acceptable terms, or at all, and lenders may be unwilling to lend funds on acceptable terms, or at all. The sale of additional equity investments may result in additional dilution to our equity holders. Debt financing would result in increased expenses and could impose new restrictive covenants. Financing arrangements may not be available to us or may not be available in amounts or on terms acceptable to us. If financing is not available, we may be forced to seek to sell assets or reduce or delay capital investments, any of which could adversely affect our business, results of operations, cash flows, and financial condition.

If we cannot generate sufficient cash flows, find other sources of capital to fund our operations and projects, make adequate capital investments to remain technologically and price competitive, or provide bonding or letters of credit required by our projects, we may need to sell additional equity investments or debt securities, or obtain debt financings. If adequate funds from these or other sources are not available on acceptable terms or at all, our ability to fund our operations, including making digital investments, develop and expand our distribution network, maintain our research and development efforts, meet any debt service obligations we take on in the future or otherwise respond to competitive pressures would be significantly impaired. Our inability to do any of the foregoing could have a material adverse effect on our business, results of operations, cash flows and financial condition.

Inflation could result in decreased value from future contractual payments and higher expenses for labor and equipment, which, in turn, could adversely impact our reputation, business, financial condition, cash flows and results of operations.

Any future increase in inflation may adversely affect our costs, including our subcontractors’ cost of labor and equipment, and may result in a decrease in value in our future contractual payments. These factors could adversely impact our reputation, business, financial condition, cash flows and results of operations.

While we believe that inflationary pressures have contributed to increased costs of labor and components that we purchase, we believe that the increased cost of these items were also due to a combination of other factors, including general supply chain issues resulting from COVID-19, other supply chain constraints, increased demand for solar systems in the U.S. and Europe and tariffs and trade regulations. We do not have information that allows us to quantify the specific amount of cost increases attributable to inflationary pressures.

Fluctuations in interest rates could adversely affect our business and financial results.

We are exposed to interest rate risk because many of our customers depend on debt financing to purchase our solar power systems. An increase in interest rates could make it difficult for our customers to obtain the financing necessary to purchase our solar power systems on favorable terms, or at all, and thus lower demand for our solar power products, reduce revenue and adversely affect our results of operations and cash flow. An increase in interest rates could lower a customer’s return on investment in a system or make alternative investments more attractive relative to solar power systems, which, in each case, could cause our customers to seek alternative investments that promise higher returns or demand higher returns from our solar power systems, which could reduce our revenue and gross margin and adversely affect our financial results. While we believe that increases in interest rates have led to higher financing costs for our customers, lower demand for our products and lower revenue than we would have otherwise experienced, we do not have information that allows us to quantify the adverse affects attributable to increased interest rates.

We may incur debt in the future, which could introduce debt servicing costs and risks to our business.

We and our subsidiaries may incur debt in the future, and such debt arrangements may restrict our ability to incur additional indebtedness, including secured indebtedness. These restrictions could inhibit our ability to pursue our business strategies. Furthermore, there is no assurance that we will be able to enter into debt instruments on acceptable terms or at all. If we were unable to satisfy financial covenants and other terms under new instruments, or obtain waivers or forbearance from our lenders, or if we were unable to obtain refinancing or new financings for our working capital, equipment, and other needs on acceptable terms if and when needed, our business would be adversely affected.

So long as the Convertible OpCo Preferred Units of OpCo remain outstanding, the Sponsor holds certain consent rights over OpCo’s ability to incur indebtedness, which could adversely affect the future business and operations of OpCo and Zeo, including by decreasing its business flexibility.

The terms of the amended and restated limited liability company agreement of OpCo (the “OpCo A&R LLC Agreement”) grant Sponsor certain consent rights with respect to certain actions, including OpCo’s incurrence of indebtedness for borrowed money, subject to certain enumerated exceptions, so long as the Convertible OpCo Preferred Units remain outstanding. As a result, OpCo needs to obtain the prior written consent of Sponsor before incurring any additional indebtedness (subject to the terms of OpCo A&R LLC Agreement). Because Sponsor has interests that are different than, or in addition to and which may conflict with, the interests of OpCo and Zeo, there is no assurance that Sponsor will consent to any proposed future incurrence of debt. Therefore, Sponsor has the ability to influence the outcome of certain matters affecting OpCo and Zeo, and OpCo may be unable to raise additional debt financing to operate during general economic or business downturns, take advantage of new business opportunities, and/or pursue its business strategies.

We have suppliers that are based or manufacture the products we sell outside the United States, which may subject us to additional business risks, including logistical complexity and political instability.

A portion of our supply agreements are with manufacturers and equipment vendors located outside of the United States. Risks we face in conducting business internationally include:

•        multiple, conflicting and changing laws and regulations relating to employment, safety, environmental protection, international trade, and other government approvals, permits, and licenses and regulatory requirements;

•        financial risks, such as longer sales and payment cycles, greater difficulty enforcing rights and remedies and capital controls or other restrictions on the transfer of funds;

•        currency fluctuations, government-fixed foreign exchange rates, the effects of currency hedging activity and the potential inability to hedge currency fluctuations;

•        the effects of Russia’s war against Ukraine and other political and economic instability, including wars, acts of terrorism, political unrest, boycotts, curtailments of trade, nationalization of assets, and other business restrictions;

•        trade barriers such as import and export requirements or restrictions, licensing requirements, tariffs, taxes and other restrictions and expenses for which we may have responsibility, which could increase the prices of our products; and

•        liabilities associated with compliance with laws (for example, the Foreign Corrupt Practices Act (“FCPA”) in the United States and similar laws outside of the United States).

•        the effects of Russia’s war on Ukraine, which, while we believe Russia’s war on Ukraine has contributed to price increases for components that we purchase, we believe that the increases to the cost of our components were also due to a combination of other factors, including general supply chain issues resulting from COVID-19, other supply chain constraints, increased demand for solar systems in the U.S. and Europe, tariffs and trade regulations, rising inflation, and higher labor, material, and shipping costs. We do not have information that allows us to quantify the specific amount of price increases attributable to Russia’s war on Ukraine and do not materially rely directly or indirectly on goods or services sources in Russia, Ukraine or Belarus or have any material business relationships, connections to, or assets in, Russia, Belarus or Ukraine.

We must work with our suppliers to effectively manage the flow of products in light of these risks. If we fail to do so, our available inventory may not correspond with product demand. If we are unable to successfully manage any such risks, any one or more could materially and adversely affect our business, results of operations, cash flows and financial condition.

We are currently dependent on third-party leasing companies to offer customers the option of leasing our solar energy systems.

As of the date of this prospectus, our customers who have entered into leasing agreements have done so solely with third-party leasing companies established and managed by White Horse Energy. Thus far, such companies have had sufficient assets to finance the purchase of systems for each of our customers who have signed agreements for leased solar energy systems to be installed on their home and for whom the installation processes have been completed. However, no assurance can be given that this will continue. Additionally, if such companies decide not to continue to provide financing for leases due to general market conditions, changes in tax benefits associated with our solar systems, concerns about our business or prospects, or any other reason, or if they materially change the terms under which they are willing to pay us to install and service leased solar energy systems, we will need to identify new leasing partners and negotiate new terms.

We intend to seek out additional third-party investors to provide financing for customers wishing to lease their solar energy systems. However, no assurance can be given that we will be able to successfully do so.

System leases represented 8% of our installations in 2023, though we expect that percentage to increase in 2024. If (i) Solar terminates their relationship with us, (ii) Solar does not have sufficient assets in the future to provide financing for customers wishing to lease their solar energy systems, or (iii) we cannot enter into new arrangements with other third-party investors to provide financing for customers wishing to lease their solar energy systems, we may be unable to continue to increase the size of our residential lease program, which could have a material, adverse effect on our business, results of operations, cash flows, and financial condition in the future.

We typically bear the cost of maintenance and repair on solar energy systems we install that are owned and leased by third-party leasing companies.

We are obligated through a maintenance services agreement to provide maintenance and repair services for solar energy systems we install that are leased by third-party leasing companies to homeowners. In the maintenance services agreement, we have agreed to maintain the leased systems for a fixed fee that is calculated to cover our future expected maintenance costs. If our solar energy systems require an above-average amount of repairs or if the cost of repairing systems were higher than our estimate, we may need to perform such services without additional compensation.

Members of our management team have interests in or are employed by other business ventures that may divert their attention from our business.

Members of our management team presently have, and may in the future have additional, ownership interests in, employment by and/or fiduciary or contractual obligations to other entities with which they are affiliated with (such as Solar). Such other ventures and entities could divert the attention of our management from our business or create conflicts of interests.

Risks Related to Regulation and Policy

Our business currently depends on the availability of utility rebates, tax credits and other benefits, tax exemptions and exclusions, and other financial incentives on the federal, state, and/or local levels. We may be adversely affected by changes in, and application of these laws or other incentives to us, and the expiration, elimination or reduction of these benefits could adversely impact our business.

Our business depends on government policies that promote and support solar energy and enhance the economic viability of owning solar energy systems. U.S. federal, state and local governmental bodies provide incentives to owners, distributors, installers and manufacturers of solar energy systems to promote solar energy. These incentives include an investment tax credit (“Commercial ITC”) and income tax credit offered by the federal government, as well as other tax credits, rebates and SRECs associated with solar energy generation. We rely on these incentives to lower our cost of capital and to attract investors, all of which enable us to lower the price we charge customers for our solar service offerings. These incentives have had a significant impact on the development of solar energy but they could change at any time, as further described below. These incentives may also expire on a particular date, end when the allocated funding is exhausted, or be reduced, terminated or repealed without notice. The financial value of certain incentives may also decrease over time.

In December 2017, the Tax Cuts and Job Acts of 2017 (the “Tax Act”) was enacted. As part of the Tax Act, the corporate income tax rate was reduced, and there were other changes, including limiting or eliminating various other deductions, credits and tax preferences. The IRA implemented a corporate alternative minimum tax of 15% of financial statement income (subject to certain adjustments) for companies that report over $1 billion in profits to shareholders; similar to existing law, business credits (including Commercial ITCs) are limited to 75% of income in excess of $25,000 (with no limit against the first $25,000). We cannot predict whether and to what extent the U.S. corporate income tax rate will change under the Biden administration. The U.S. Congress is constantly considering changes to the tax code. Further limitations on, or elimination of, the tax benefits that support the financing of solar energy under current U.S. law could significantly and adversely impact our business.

Our business model also relies on multiple tax exemptions offered at the state and local levels. For example, some states have property tax exemptions that exempt the value of solar energy systems in determining values for calculation of local and state real and personal property taxes. State and local tax exemptions can have sunset dates, triggers for loss of the exemption, and can be changed by state legislatures and other regulators, and if solar energy systems were not exempt from such taxes, the property taxes payable by customers would be higher, which could offset any potential savings our solar service offerings could offer. Similarly, if state or local legislatures or tax administrators impose property taxes on third-party owners of solar energy systems, solar companies like us would be subject to higher costs.

In general, we rely on certain state and local tax exemptions that apply to the sale of equipment, sale of power, or both. These state and local tax exemptions can expire, can be changed by state legislatures, or their application to us can be challenged by regulators, tax administrators, or court rulings. Any changes to, or efforts to overturn, federal and state laws, regulations or policies that are supportive of solar energy generation or that remove costs or other limitations on other types of energy generation that compete with solar energy projects could materially and adversely affect our business.

We rely on certain utility rate structures, such as net metering, to offer competitive pricing to customers, and changes to those policies may significantly reduce demand for electricity from our solar energy systems.

As of December 31, 2023, a substantial majority of states have adopted net metering policies, including Florida, Texas, Arkansas and Missouri. Net metering policies allow homeowners to serve their own energy load using on-site generation while avoiding the full retail volumetric charge for electricity. Electricity that is generated by a solar energy system and consumed on-site avoids a retail energy purchase from the applicable utility, and excess electricity that is exported back to the electric grid generates a retail credit within a homeowner’s monthly billing period. At the end of the monthly billing period, if the homeowner has generated excess electricity within that month, the homeowner typically carries forward a credit for any excess electricity to be offset against future utility energy purchases. At the end of an annual billing period or calendar year, utilities either continue to carry forward a credit, or reconcile the homeowner’s final annual or calendar year bill using different rates (including zero credit) for the exported electricity.

Utilities, their trade associations, and fossil fuel interests in the country are currently challenging net metering policies, and seeking to eliminate them, cap them, reduce the value of the credit provided to homeowners for excess generation, or impose charges on homeowners that have net metering.

A few states have moved away from traditional full retail net metering and instead values excess generation by customers’ solar systems in various ways. For example, in 2017, Nevada enacted legislation to restore net metering at a reduced credit and guarantee new customers the net metering rate in effect at the time they applied for interconnection for 20 years. In 2016, the Arizona Corporation Commission replaced retail net metering with a net-feed in tariff (a fixed export rate). Some states set limits on the total percentage of a utility’s customers that can adopt net metering or set a timeline to evaluate net metering successor tariffs. For example, South Carolina passed legislation in 2019 that required review of net metering after two years. In 2021, the South Carolina Public Service Commission approved a portion of Duke Energy’s proposal that maintains the net metering framework with time-of-use rates and rejected a proposal from Dominion Energy to eliminate net metering altogether. In 2021 legislation, Illinois changed its net metering threshold from a percentage of customers to full retail net metering offered to a date certain (December 31, 2024) with a directed successor tariff that includes values that distributed resources provide to the distribution grid. New Jersey currently has no net metering cap; however, it has a threshold that triggers commission review of its net metering policy. States we serve now or in the future may adopt similar policies or net metering caps. If the net metering caps in these jurisdictions are reached without an extension of net metering policies, homeowners in those jurisdictions will not have access to the economic value proposition net metering provides. Our ability to sell our solar

service offerings may be adversely impacted by the failure to extend existing limits to net metering or the elimination of currently existing net metering policies. The failure to adopt a net metering policy where it currently is not in place would pose a barrier to entry in those states. On April 26, 2022, Florida Governor DeSantis vetoed legislation that would have established a threshold date and percentage trigger when retail net metering would have faced declines in the immediate export rate.

Additionally, the imposition of charges that only or disproportionately impact homeowners that have solar energy systems, or the introduction of rate designs mentioned above, would adversely impact our business. Because fixed charges cannot easily be avoided with the installation of an on-site battery, which can mitigate or eliminate the negative impacts of net metering changes, these fixed charges have the potential to cause a more significant adverse impact. In June of 2021, two of four commissioners of FERC, including its chairperson, issued a letter stating there was a “strong case” such fixed charges in Alabama “may be violating the Commission’s PURPA regulations, undermining the statute’s purpose of encouraging Qualifying Facilities,” which is the Commission’s term for on-site generation. Litigation regarding the legality of these charges is ongoing in federal court. Most recently, on April 26, 2022, Florida Governor DeSantis vetoed legislation that would have allowed investor-owned utilities to petition the Public Service Commission for the ability to add fixed charges on solar customers. As part of the California Public Utilities Commission (“CPUC”) final decision on December 15, 2022, the CPUC rejected a solar specific fixed charge on solar customers.

Electric utility policies, statutes, and regulations and changes to such statutes or regulations may present technical, regulatory and economic barriers to the purchase and use of our solar energy offerings that may significantly reduce demand for such offerings.

Federal, state and local government policies, statutes and regulations concerning electricity heavily influence the market for our solar energy offerings and are constantly evolving. These statutes, regulations, and administrative rulings relate to electricity pricing, net metering, consumer protection, incentives, taxation, competition with utilities and the interconnection of homeowner-owned and third party-owned solar energy systems to the electrical grid. These policies, statutes and regulations are constantly evolving. Governments, often acting through state utility or public service commissions, change and adopt different rates for residential customers on a regular basis and these changes can have a negative impact on our ability to deliver savings, or energy bill management, to customers.

In addition, many utilities, their trade associations, and fossil fuel interests in the country, which have significantly greater economic, technical, operational, and political resources than the residential solar industry, are currently challenging solar-related policies to reduce the competitiveness of residential solar energy. Any adverse changes in solar-related policies could have a negative impact on our business and prospects.

We are not currently regulated as a utility under applicable laws, but we may be subject to regulation as a utility in the future or become subject to new federal and state regulations for any additional solar service offerings we may introduce in the future.

Most federal, state, and municipal laws do not currently regulate us as a utility. As a result, we are not subject to the various regulatory requirements applicable to U.S. utilities. However, any federal, state, local or other applicable regulations could place significant restrictions on our ability to operate our business and execute our business plan by prohibiting or otherwise restricting our sale of electricity. These regulatory requirements could include restricting our sale of electricity, as well as regulating the price of our solar service offerings. If we become subject to the same regulatory authorities as utilities or if new regulatory bodies are established to oversee our business, our operating costs could materially increase.

Changes to the applicable laws and regulations governing direct-to-home sales and marketing may limit or restrict our ability to effectively compete.

We utilize a direct-to-home sales model as a primary sales channel and are vulnerable to changes in laws and regulations related to direct sales and marketing that could impose additional limitations on unsolicited residential sales calls and may impose additional restrictions such as adjustments to our marketing materials and direct-selling processes, and new training for personnel. If additional laws and regulations affecting direct sales and marketing are passed in the markets in which we operate, it would take time to train our sales professionals to comply with such laws, and we may be exposed to fines or other penalties for violations of such laws. If we fail to compete effectively through our direct-selling efforts, our financial condition, results of operations and growth prospects could be adversely affected.

Increases in the cost or reduction in supply of solar energy system and energy storage system components due to tariffs or trade restrictions imposed by the U.S. government could have an adverse effect on our business, financial condition and results of operations.

China is a major producer of solar cells and other solar products. Certain solar cells, modules, laminates and panels from China are subject to various U.S. antidumping and countervailing duty rates, depending on the exporter supplying the product, imposed by the U.S. government as a result of determinations that the U.S. was materially injured as a result of such imports being sold at less than fair value and subsidized by the Chinese government. Historically, we and our subcontractors regularly surveyed the market to identify multiple alternative locations for product manufacturers. Nonetheless, many of the solar products we purchase are from manufacturers in China or from manufacturers in other jurisdictions who rely, in part, on products sourced in China. If alternative sources are not available on competitive terms in the future, we and our subcontractors may be required to purchase these products from manufacturers in China. In addition, tariffs on solar cells, modules and inverters in China may put upward pressure on prices of these products in other jurisdictions from which we or our subcontractors currently purchase equipment, which could reduce our ability to offer competitive pricing to potential customers.

The antidumping and countervailing duties discussed above are subject to annual review and may be increased or decreased. Furthermore, under Section 301 of the Trade Act of 1974, the Office of the United States Trade Representative (“USTR”) imposed tariffs on $200 billion worth of imports from China, including inverters and certain AC modules and non-lithium-ion batteries, effective September 24, 2018. In May 2019, the tariffs were increased from 10% to 25% and may be raised by the USTR in the future. Since these tariffs impact the purchase price of the solar products, these tariffs raise the cost associated with purchasing these solar products from China and reduce the competitive pressure on providers of solar cells not subject to these tariffs.

In August 2021, an anonymous trade group filed a petition with the U.S. Department of Commerce (the “Department of Commerce”) requesting an investigation into whether solar panels and cells imported from Malaysia, Thailand and Vietnam are circumventing anti-dumping and countervailing duties imposed on solar products manufactured in China. The group also requested the imposition of tariffs on such imports ranging from 50% – 250%. In November 2021, the Department of Commerce rejected the petition, citing the petitioners’ ongoing anonymity as one of the reasons for its decision. In March 2022, the Department of Commerce announced it is initiating country-wide circumvention inquiries to determine whether imports of solar cell and modules produced in Cambodia, Malaysia, Thailand and Vietnam that use components from China are circumventing anti-dumping and countervailing duty orders on solar cells and modules from China. The Department of Commerce’s inquiries were initiated pursuant to a petition filed by Auxin Solar, Inc. on February 8, 2022.

While the investigation remains ongoing, in December 2022, the Department of Commerce announced its preliminary determination in the investigation. In its determination, the Department of Commerce found that certain Chinese solar manufacturers circumvented U.S. import duties by routing some of their operations through Cambodia, Malaysia, Thailand and Vietnam. Given the Department of Commerce preliminarily found that circumvention was occurring through each of the four Southeast Asian countries, the Department of Commerce made a “country-wide” circumvention finding, which designates each country as one through which solar cells and modules are being circumvented from China. However, companies in these countries will be permitted to certify they are not circumventing the U.S. import duties, in which case the circumvention findings may not apply. The Department of Commerce will take a number of additional steps before issuing a final determination. In particular, the Department of Commerce will conduct in-person audits to verify the information that was the basis of its preliminary determination. Furthermore, the Department of Commerce will gather public comments on the preliminary determination to consider before issuing its final determination. Notably, however, on June 6, 2022, the President of the United States issued an emergency declaration establishing a tariff exemption of two years for solar panels and cells imported from Cambodia, Malaysia, Thailand and Vietnam, delaying the possibility of the imposition of dumping duties until the end of such two-year period. In September 2022, the Department of Commerce issued its final rule effectuating the two-year exemption period, and new dumping duties will not be imposed on solar panels and cells imported from Cambodia, Malaysia, Thailand and Vietnam until the earlier of two years after the date of the emergency declaration or when the emergency is terminated. Tariffs may be reinstated following the exemption period, but imports of solar cells and modules will not be subject to retroactive tariffs during the exemption period. The addition of new dumping duties would significantly disrupt the supply of solar cells and modules to customers in the U.S., as a large percentage of solar cells and modules used in the U.S. are imported from Cambodia, Malaysia, Thailand and Vietnam. If imposed, these or similar tariffs could put upward pressure on prices of these solar products, which could reduce our ability to offer competitive pricing to potential customers.

In addition, in December 2021, the U.S. International Trade Commission recommended the President extend tariffs initially imposed in 2018 on imported crystalline silicon PV cells and modules for another four years, until 2026. Under Presidential Proclamation 10339, published in February 2022, President Biden extended the tariff beyond the scheduled expiration date of February 6, 2022, with an initial tariff of 14.75%, which will gradually be reduced to 14% by the eighth year of the measure. Since such actions increase the cost of imported solar products, to the extent we or our subcontractors use imported solar products or domestic producers are able to raise their prices for their solar products, the overall cost of the solar energy systems will increase, which could inhibit our ability to offer competitive pricing in certain markets.

Additionally, the U.S. government has imposed various trade restrictions on Chinese entities determined to be acting contrary to U.S. foreign policy and national security interests. For example, the Department of Commerce’s Bureau of Industry and Security has added a number of Chinese entities to its entity list for enabling human rights abuses in the XUAR or for procuring U.S. technology to advance China’s military modernization efforts, thereby imposing severe trade restrictions against these designated entities. Moreover, in June 2021, U.S. Customs and Border Protection issued a Withhold Release Order pursuant to Section 307 of the Tariff Act of 1930 excluding the entry into U.S. commerce of silica-based products (such as polysilicon) manufactured by Hoshine Silicon Industry Co. Ltd. (“Hoshine”) and related companies, as well as goods made using those products, based on allegations related to Hoshine labor practices in the XUAR to manufacture such products. Additionally, in December 2021, Congress passed the UFLPA, which, with limited exception, prohibits the importation of all goods or articles mined or produced in whole or in part in the XUAR, or goods or articles mined or produced by entities working with the XUAR government to recruit, transport or receive forced labor from the XUAR. To date, intensive examinations, withhold release orders, and related governmental procedures have resulted in supply chain and operational delays throughout the industry. Although we maintain policies and procedures designed to maintain compliance with applicable governmental laws and regulations, these and other similar trade restrictions that may be imposed in the future may cause us to incur substantially higher compliance and due diligence costs in connection with procurement and have the effect of restricting the global supply of, and raising prices for, polysilicon and solar products, which could increase the overall cost of solar energy systems, reduce our ability to offer competitive pricing in certain markets and adversely impact our business and results of operations. Further, any operational delays or other supply chain disruption resulting from the human rights concerns or any of the supply chain risks articulated above, associated governmental responses, or a desire to source products, components, or materials from other manufacturers or regions could result in shipping, sales and installation delays, cancellations, penalty payments, or loss of revenue and market share, or may cause our key suppliers to seek to re-negotiate terms and pricing with us, any of which could have a material adverse effect on our business, results of operations, cash flows, and financial condition.

While we believe the tariffs and trade regulations described above have contributed to price increases for components that we purchase, we believe that these price increases were due largely to a combination of other factors, including supply chain constraints, increased demand for solar systems in the U.S. and Europe, rising inflation, and higher labor, material, and shipping costs. We do not have information that allows us to quantify the specific amount of price increases attributable to the tariffs and trade regulations described. We cannot predict what additional actions the U.S. may adopt with respect to tariffs or other trade regulations or what actions may be taken by other countries in retaliation for such measures. The tariffs described above, the adoption and expansion of trade restrictions, the occurrence of a trade war or other governmental action related to tariffs, trade agreements or related policies have the potential to adversely impact our supply chain and access to equipment, our costs and ability to economically serve certain markets. If additional measures are imposed or other negotiated outcomes occur, our ability or the ability of our subcontractors to purchase these products on competitive terms or to access specialized technologies from other countries could be further limited, which could adversely affect our business, financial condition and results of operations.

Any failure to comply with laws and regulations relating to interactions by us or third parties (such as our dealers and subcontractors) with customers or with licensing requirements applicable to our business could result in negative publicity, claims, investigations and litigation, and may adversely affect our financial performance.

Our business involves transactions with customers. We and our subcontractors and dealers must comply with numerous federal, state and local laws and regulations that govern matters relating to our interactions with customers, including those pertaining to privacy and data security, home improvement contracts, warranties and direct-to-home solicitation, along with certain rules and regulations specific to the marketing and sale of residential solar products and services. These laws and regulations are dynamic and subject to potentially differing interpretations, and various federal, state

and local legislative and regulatory bodies may expand current laws or regulations, or enact new laws and regulations, regarding these matters. Changes in these laws or regulations or their interpretation could dramatically affect how we do business, acquire customers, and manage and use information we collect from and about current and prospective customers and the costs associated therewith. We strive to comply with all applicable laws and regulations relating to our interactions with customers. It is possible, however, that these requirements may be interpreted and applied in a manner that is inconsistent from one jurisdiction to another and may conflict with other rules or our practices. Noncompliance with any such laws or regulations, or the perception that we or our subcontractors or dealers have violated such laws or regulations or engaged in deceptive practices that could result in a violation, could also expose us to claims, proceedings, litigation and investigations by private parties and regulatory authorities, as well as substantial fines and negative publicity, each of which may materially and adversely affect our business. We have incurred, and will continue to incur, significant expenses to comply with such laws and regulations, and increased regulation of matters relating to our interactions with customers could require us to modify our operations and incur significant additional expenses, which could have an adverse effect on our business, financial condition, and results of operations.

Any investigations, actions, adoption or amendment of regulations relating to the marketing of our products could divert management’s attention from our business, require us to modify our operations and incur significant additional expenses, which could have an adverse effect on our business, financial condition, and results of operations or could reduce the number of our potential customers.

We cannot ensure that our sales professionals and other personnel will always comply with our standard practices and policies, as well as applicable laws and regulations. In any of the numerous interactions between our sales professionals or other personnel and our customers or potential customers, our sales professionals or other personnel may, without our knowledge and despite our efforts to effectively train them and enforce compliance, engage in conduct that is or may be prohibited under our standard practices and policies and applicable laws and regulations. Any such non-compliance, or the perception of non-compliance, may expose us to claims, proceedings, litigation, investigations or enforcement actions by private parties or regulatory authorities, as well as substantial fines and negative publicity, each of which may materially and adversely affect our business and reputation. We have incurred, and will continue to incur, significant expenses to comply with the laws, regulations and industry standards that apply to us.

In addition, our affiliations with third-party dealers and subcontractors may subject us to alleged liability in connection with actual or alleged violations of law by such third parties, whether or not actually attributable to us, which may expose us to significant damages and penalties, and we may incur substantial expenses in defending against legal actions related to third parties, whether or not we are ultimately found liable.

Compliance with environmental laws and regulations can be expensive, and noncompliance with these laws and regulations may result in adverse publicity and potentially significant monetary damages and fines.

We are required to comply with all applicable foreign, U.S. federal, state, and local laws and regulations regarding pollution control and protection of safety and the environment. These law and regulations may include obligations relating to the release, emissions or discharge of materials into the air, water and ground, the generation, storage, handling, use, transportation and disposal of hazardous materials and wastes and the health and safety of our employees and other persons. Under some statutes and regulations, a government agency, or other parties, may seek recovery and response costs from owners or operators of property where releases of hazardous substances have occurred or are ongoing, even if the owner or operator was not responsible for such release or otherwise at fault. We use solar energy system and energy storage components that may contain toxic, volatile and otherwise hazardous substances in our operations. Any failure by us to control the use of, transport of, or to restrict adequately the discharge of, hazardous substances could subject us to, among other matters, potentially significant monetary damages and fines or liabilities or suspensions of our business operations. In addition, if more stringent laws and regulations are adopted in the future, the costs of compliance with these new laws and regulations could be substantial. If we fail to comply with present or future environmental laws and regulations, we may be required to pay substantial fines, suspend production or cease operations, or be subjected to other sanctions. Private parties may also have the right to pursue legal actions to enforce compliance as well as to seek damages for non-compliance with environmental laws and regulations or for personal injury or property damage.

In addition, U.S. legislation includes disclosure requirements regarding the use of “conflict” minerals mined from the Democratic Republic of Congo and adjoining countries and procedures regarding a manufacturer’s efforts to prevent the sourcing of such “conflict” minerals. We have incurred and will incur additional costs to comply with the

disclosure requirements, including costs related to determining the source of any of the relevant minerals and metals used in our products. The implementation of these requirements could affect the sourcing and availability of minerals used in the manufacture of solar products. As a result, there may only be a limited pool of suppliers who provide conflict-free minerals, and we cannot be certain that we will be able to obtain products in sufficient quantities or at competitive prices. Since our supply chain is complex, we have not been able to sufficiently verify, and in the future, we may not be able to sufficiently verify, the origins for these conflict minerals used in our products. As a result, we may face reputational challenges with our customers and other stakeholders if we are unable to sufficiently verify the origins for all conflict minerals used in our products.

Compliance with health and safety laws and regulations can be complex, and noncompliance with these laws and regulations may result in potentially significant monetary damages and fines.

We are subject to a number of federal and state laws and regulations, including the federal Occupational Safety and Health Act (“OSHA”) and comparable state statues, establishing requirements to protect the health and safety of workers. The OSHA hazard communication standard, the US EPA community right-to-know regulations under Title III of the federal Superfund Amendment and Reauthorization Act, and comparable state statutes, require maintenance of information about hazardous materials used or produced in operations and provision of this information to employees, state and local government authorities, and citizens. Other OSHA standards regulate specific worker safety aspects of our operations. Substantial fines and penalties can be imposed, and orders or injunctions limiting or prohibiting certain operations may be issued, in connection with any failure to comply with these laws and regulations.

Our business is subject to complex and evolving U.S. and international privacy and data protection laws, rules, policies and other obligations. Many of these laws and regulations are subject to change and uncertain interpretation and could result in claims, increased cost of operations or otherwise harm our business.

Consumer personal privacy and data security have become significant issues and the subject of rapidly evolving regulation. Furthermore, federal, state and local government bodies or agencies have in the past adopted, and may in the future adopt, more laws and regulations affecting data privacy. For example, new California legislation and regulations afford California consumers an array of new rights, including the right to be informed about what kinds of personal information companies have collected and the purpose for the collection. Complying with such laws or regulations, including in connection with any future expansion into new states (e.g., California), may significantly impact our business activities and require substantial compliance costs that adversely affect our business, operating results, prospects and financial condition. To date, we have not experienced substantial compliance costs in connection with fulfilling the requirements with any such laws or regulations. However, we cannot be certain that compliance costs will not increase in the future with respect to such laws or regulations. Furthermore, if we expand to foreign markets we will be subject to additional privacy and data protection laws, such as the General Data Protection Regulation in the European Union.

We operate a call center that uses personal information to conduct follow-up marketing calls to prospective customers of our solar energy systems. The out-going marketing calls we make are subject to the Telephone Consumer Protection Act (“TCPA”) and any failure to comply with the TCPA could result in significant fines and potential litigation from consumers.

Any inability to adequately address privacy and security concerns, even if unfounded, or comply with applicable privacy and data protection laws, regulations and policies, could result in additional cost and liability to us, damage our reputation, inhibit sales and adversely affect our business. Furthermore, the costs of compliance with, and other burdens imposed by, the laws, regulations and policies that are applicable to our business may limit the use and adoption of, and reduce the overall demand for, our solutions. If we are not able to adjust to changing laws, regulations and standards related to privacy or security, our business may be harmed.

A change in our effective tax rate could have a significant adverse impact on our business, and an adverse outcome resulting from examination of our income or other tax returns could adversely affect our results.

A number of factors may adversely affect our future effective tax rates, such as the jurisdictions in which our profits are determined to be earned and taxed; changes in the valuation of our deferred tax assets and liabilities; adjustments to estimated taxes upon finalization of various tax returns; adjustments to our interpretation of transfer pricing standards; changes in available tax credits, grants and other incentives; changes in stock-based compensation expense; the availability of loss or credit carryforwards to offset taxable income; changes in tax laws or the interpretation of

such tax laws (for example federal and state taxes); and changes in U.S. generally accepted accounting principles (“GAAP”). A change in our effective tax rate due to any of these factors may adversely affect our future results from operations.

Significant judgment is required to determine the recognition and measurement attributes prescribed in the accounting guidance for uncertainty in income taxes. The accounting guidance for uncertainty in income taxes applies to all income tax positions, including the potential recovery of previously paid taxes, which if settled unfavorably could adversely affect our provision for income taxes. In addition, we are subject to examination of our income tax returns by various tax authorities. We regularly assess the likelihood of adverse outcomes resulting from any examination to determine the adequacy of our provision for income taxes. An adverse determination of an examination could have an adverse effect on our results of operations and financial condition.

Additionally, U.S. tax reform may lead to further changes in (or departure from) these norms. As these and other tax laws and related regulations change, our results of operations, cash flows, and financial condition could be materially impacted. Given the unpredictability of these possible changes and their potential interdependency, it is very difficult to assess whether the overall effect of such potential tax changes would be cumulatively positive or negative for our earnings and cash flow.

Risks Related to This Offering and Ownership of Zeo Securities

Sales of a substantial number of our securities in the public market by the selling securityholders and/or by our existing securityholders could cause the price of our shares of Class A Common Stock and Warrants to fall.

The selling securityholders can sell, under this prospectus, up to

•        4,000,004 outstanding shares of Class A Common Stock issued to the Sponsor and certain former holders of ESGEN Class B ordinary shares, issued to such holders at an equity consideration value of $10.00 per share;

•        50,000 outstanding shares of Class A Common Stock issued to Piper Sandler & Co. at an equity consideration value of $5.00 per share;

•        1,838,430 shares of Class A Common Stock issuable upon exchange of an equivalent number of Convertible OpCo Preferred Units and Class V Common Stock issued to the Sponsor pursuant to the Sponsor Subscription Agreement at an equity consideration value of $10.00 per share;

•        33,730,000 shares of Class A Common Stock issuable upon exchange of an equivalent number of Exchangeable OpCo Units and Class V Common Stock issued to the Sellers pursuant to the Business Combination Agreement at an equity consideration value of $10.00 per share; and

•        500,000 shares of Class A Common Stock issuable to Sun Managers, LLC upon potential forfeiture of an equivalent number of shares of Class A Common Stock issued to Sponsor and certain former holders of ESGEN Class B ordinary shares.

However, the Sponsor and each other shareholders party to the Amendment to the Letter Agreement and each Seller party to the Lock-Up Agreement is prohibited from transferring any securities of Zeo until the earlier of (i) six months after the Closing and (ii) subsequent to the Closing, (a) satisfaction of the Early Lock-Up Termination or (b) the date on which Zeo completes a PubCo Sale (as defined in the Lock-Up Agreement), these shares of Class A Common Stock may be sold after the expiration or early termination or release of the respective applicable lock-up under the Amendment to the Letter Agreement or Lock-Up Agreement, as applicable. Additionally, the Initial Shareholders have agreed not to transfer an aggregate of 500,000 shares of Class A Common Stock until two years after the Closing (with such shares being forfeited upon the occurrence of a Convertible OpCo Preferred Unit Optional Conversion or a Convertible OpCo Preferred Unit Redemption within two years after Closing).

The sale of all or a portion of the securities being offered in this prospectus could result in a significant decline in the public trading price of our securities. Despite such a decline in the public trading price, some of the selling securityholders may still experience a positive rate of return on the securities they purchased due to the price at which such selling securityholder initially purchased the securities. See “Certain existing stockholders purchased, or may purchase, securities in the Company at a price below the current trading price of such securities, and may experience a positive rate of return based on the current trading price. Future investors in the Company may not experience a similar rate of return.” below.

In addition, sales of a substantial number of our shares of Class A Common Stock and/or Warrants in the public market by the selling securityholders and/or by our other existing securityholders, or the perception that those sales might occur, could depress the market price of our Class A Common Stock and Warrants and could impair our ability to raise capital through the sale of additional equity securities. We are unable to predict the effect that such sales may have on the prevailing market price of our Class A Common Stock and Warrants.

Sales, or the perception of sales, of our Class A Common Stock, including those shares registered in this registration statement, by us or our existing stockholders in the public market could cause the market price for our Class A Common Stock to decline.

The sale of substantial amounts of shares Class A Common Stock in the public market, or the perception that such sales could occur, could harm the prevailing market price of the Class A Common Stock. These sales, or the possibility that these sales may occur, also might make it more difficult for us to sell equity securities in the future at a time and at a price that we deem appropriate.

Upon the effectiveness of this registration statement and the expiration or waiver of the lock-ups described in the risk factor above, shares held by certain of our stockholders will be eligible for resale, subject to, in the case of certain securityholders, volume, manner of sale and other limitations under Rule 144. As restrictions on resale end, the market price of shares of Class A Common Stock could drop significantly if the holders of these shares sell them or are perceived by the market as intending to sell them. These factors could also make it more difficult for us to raise additional funds through future offerings of our shares of common stock or other securities.

In addition, the shares of our Class A Common Stock reserved for future issuance under the 2024 Plan will become eligible for sale in the public market once those shares are issued, subject to provisions relating to various vesting agreements, lock-up agreements and, in some cases, limitations on volume and manner of sale by affiliates under Rule 144, as applicable. The number of shares reserved for future issuance under the 2024 Plan currently equals 3,220,400 shares of Class A Common Stock.

We expect to file one or more registration statements on Form S-8 under the Securities Act to register shares of our Class A Common Stock or securities convertible into or exchangeable for shares of our Class A Common Stock issued pursuant to our equity incentive plans. Any such Form S-8 registration statements will automatically become effective upon filing. Accordingly, shares registered under such registration statements will be available for sale in the open market. The initial registration statement on Form S-8 is expected to cover approximately 3,220,400 shares of Class A Common Stock.

Certain existing securityholders purchased, or may purchase, securities in the Company at a price below the current trading price of such securities, and may experience a positive rate of return based on the current trading price. Future investors in the Company may not experience a similar rate of return.

Certain stockholders in the Company, including certain of the selling securityholders, acquired, or may acquire, shares of our Class A Common Stock or Warrants at prices below the current trading price of our Class A Common Stock or Warrants, as applicable, and may experience a positive rate of return based on the current trading price.

For example, the Sponsor and the other Initial Shareholders can earn a positive rate of return on their investment if the trading price of Class A Common Stock is approximately $2.04 or more per share. Public stockholders may not be able to experience the same positive rates of return on securities they purchase due to the low price at which the Sponsor and the other Initial Shareholders purchased shares of our Class A Common Stock and Warrants.

Our management team has limited experience managing a public company, and regulatory compliance obligations may divert its attention from the day-to-day management of our businesses.

Most of the individuals who now constitute our management team have limited to no experience managing a publicly-traded company, interacting with public company investors and complying with the increasingly complex laws pertaining to public companies. Our management team may not successfully or efficiently manage our transition to being a public company subject to significant regulatory oversight and reporting obligations under federal securities laws and the continuous scrutiny of securities analysts and investors. These new obligations and constituents will require significant attention from our senior management and could divert their attention away from the day-to-day

management of our businesses, which could adversely affect our businesses. It is probable that we will be required to expand our employee base and hire additional employees to support our operations as a public company, which would increase our operating costs in future periods.

We will incur significant costs as a result of operating as a public company.

We are subject to the reporting requirements of the Exchange Act, the Sarbanes-Oxley Act, the Dodd-Frank Wall Street Reform and Consumer Protection Act of 2010, Nasdaq listing requirements and other applicable securities laws and regulations. The expenses incurred by public companies generally for reporting and corporate governance purposes are greater than those for private companies. For example, the Exchange Act requires, among other things, that we file annual, quarterly, and current reports with respect to our business, financial condition, and results of operations. Compliance with these rules and regulations will increase our legal and financial compliance costs, and increase demand on our systems, particularly after we are no longer an emerging growth company. In addition, as a public company, we may be subject to stockholder activism, which can lead to additional substantial costs, distract management, and impact the manner in which we operate our business in ways we cannot currently anticipate. As a result of disclosure of information in this prospectus and in filings required of a public company, our business and financial condition will become more visible, which may result in threatened or actual litigation, including by competitors. We expect these rules and regulations to increase our legal and financial compliance costs and to make some activities more difficult, time-consuming, and costly, although we are currently unable to estimate these costs with any degree of certainty.

We also expect that being a public company and being subject to new rules and regulations will make it more expensive for us to obtain directors and officers liability insurance, and we may be required to accept reduced coverage or incur substantially higher costs to obtain coverage. These laws and regulations could also make it more difficult for us to attract and retain qualified persons to serve on the Board, committees of the Board or as our executive officers. Furthermore, if we are unable to satisfy our obligations as a public company, we could be subject to delisting of Class A Common Stock, fines, sanctions, and other regulatory action and potentially civil litigation. These factors may therefore strain our resources, divert management’s attention, and affect our ability to attract and retain qualified board members and executive officers.

As a public reporting company, we are subject to rules and regulations established from time to time by the SEC and Public Company Accounting Oversight Board regarding our internal control over financial reporting. If we fail to establish and maintain effective internal control over financial reporting and disclosure controls and procedures, we may not be able to accurately report our financial results or report them in a timely manner, which could adversely affect our business.

We are a public reporting company subject to the rules and regulations established from time to time by the SEC and the Public Company Accounting Oversight Board. These rules and regulations require, among other things, that we establish and periodically evaluate procedures with respect to our internal control over financial reporting. Reporting obligations as a public company are likely to place a considerable strain on our financial and management systems, processes, and controls, as well as on our personnel.

As a public company, we are required to document and test our internal control over financial reporting pursuant to Section 404 of the Sarbanes-Oxley Act so that our management can certify as to the effectiveness of our internal control over financial reporting by the time our second annual report is filed with the SEC and thereafter, which requires us to document and make significant changes to our internal control over financial reporting. As a public company, we are subject to the reporting requirements of the Exchange Act, the Sarbanes-Oxley Act and the Dodd-Frank Wall Street Reform and Consumer Protection Act of 2010, as well as rules adopted, and to be adopted, by the SEC and Nasdaq, and other applicable securities rules and regulations, which impose various requirements on public companies, including the establishment and maintenance of effective disclosure and financial controls and changes in corporate governance practices. Our management and other personnel need to devote a substantial amount of time to these public company requirements. Moreover, we expect these rules and regulations to substantially increase our legal and financial compliance costs and to make some activities more time-consuming and costly. We may need to hire additional legal, accounting and financial staff with appropriate public company experience and technical accounting knowledge and maintain an internal audit function.

Likewise, as a public company, we may lose our status as an “emerging growth company,” as defined in the JOBS Act, and become subject to the SEC’s internal control over financial reporting management and auditor attestation requirements in the year in which we are deemed to be a large accelerated filer, which would occur once we are subject to Exchange Act reporting requirements for 12 months, have filed at least one SEC annual report and the market value of our common equity held by non-affiliates equals or exceeds $700 million as of the end of the prior fiscal year’s second fiscal quarter. If we become subject to the SEC’s internal control reporting and attestation requirements, we might not be able to complete our evaluation, testing and any required remediation in a timely fashion. In addition, our current controls and any new controls that we develop may become inadequate because of poor design and changes in our business, including increased complexity resulting from any international expansion. Any failure to implement and maintain effective internal controls over financial reporting could adversely affect the results of assessments by our independent registered public accounting firm and their attestation reports.

We are continuing to develop and refine our disclosure controls and other procedures that are designed to ensure that information required to be disclosed by us in the reports that we will file with the SEC is recorded, processed, summarized, and reported within the time periods specified in SEC rules and forms and that information required to be disclosed in reports under the Exchange Act is accumulated and communicated to our principal executive and financial officers. We are also continuing to improve our internal control over financial reporting, which includes hiring additional accounting and financial personnel to implement such processes and controls. We expect to incur costs related to implementing an internal audit and compliance function in the upcoming years to further improve our internal control environment.

We have identified material weaknesses in our internal controls over financial reporting. If we are unable to remediate these material weaknesses, if management identifies additional material weaknesses in the future or if we otherwise fail to maintain effective internal controls over financial reporting, we may not be able to accurately or timely report our financial position or results of operations, which may adversely affect our business and stock price or cause our access to the capital markets to be impaired.

We have identified material weaknesses in our internal controls over financial reporting. A material weakness is a deficiency, or combination of deficiencies, in internal controls over financial reporting such that there is a reasonable possibility that a material misstatement of our annual or interim financial statements will not be prevented or detected on a timely basis. These material weaknesses are listed below:

•        Ineffective controls over period end financial disclosure and reporting processes, including not timely performing certain reconciliations and the completeness and accuracy of those reconciliations, and lack of effectiveness of controls over accurate accounting and financial reporting and reviewing the underlying financial statement elements that led to, for example, inappropriate revenue recognition, preparing consolidating financial statements that did not contain the required eliminating journal entries for intercompany transactions, and recording incorrect journal entries that also did not have the sufficient review and approval.

•        Insufficient controls around the review of certain technical accounting matters and related entries due to lack of sufficient staffing of adequate accounting resources.

•        Inadequate segregation of duties in various key processes, including user access within the information technology control environment.

•        Lack of documentation of policies and procedures including cybersecurity, user access reviews, and sufficient change management around the information technology control environment.

•        Incomplete mapping of our risk assessment to our accounting processes and control objectives and a lack of formality in our internal control activities, especially related to management review-type controls.

These control deficiencies could result in a misstatement in our accounts or disclosures that would result in a material misstatement to our financial statements that would not be prevented or detected. Accordingly, we determined that these control deficiencies constitute material weaknesses.

We are in the early stages of designing and implementing a plan to remediate the material weaknesses identified.

Our plan includes the below:

•        Designing and implementing a risk assessment process supporting the identification of risks.

•        Implementing systems and controls to enhance our review of significant accounting transactions and other new technical accounting and financial reporting issues and preparing and reviewing accounting memoranda addressing these issues.

•        Improving our internal control policies and procedures to specifically address controls around segregation of duties, cybersecurity, user access reviews, and changes in management.

•        Implementing specific user access, segregation of duties and change management controls within our financial reporting IT systems.

•        Hiring additional experienced accounting, financial reporting and internal control personnel and changing roles and responsibilities of our personnel as we transition to being a public company and are required to comply with Section 404 of the Sarbanes-Oxley Act (“Section 404”). We are in the process of hiring additional resources and we are engaging with a third-party consulting firm to assist us with our formal internal control plan and to provide accounting services related to complex accounting transactions.

•        Implementing controls to enable an effective and timely review of period-end close procedures.

•        Implementing controls to enable an accurate and timely review of accounting records that support our accounting processes and maintain documents for internal accounting reviews.

We cannot assure you that these measures will significantly improve or remediate the material weaknesses described above. The implementation of these remediation measures is in the early stages and will require validation and testing of the design and operating effectiveness of our internal controls over a sustained period of financial reporting cycles and, as a result, the timing of when we will be able to fully remediate the material weaknesses is uncertain. If the steps we take do not remediate the material weaknesses in a timely manner, there could be a reasonable possibility that these control deficiencies or others may result in a material misstatement of our annual or interim financial statements that would not be prevented or detected on a timely basis. This, in turn, could jeopardize our ability to comply with our reporting obligations, limit our ability to access the capital markets and adversely impact our stock price.

We and our independent registered public accounting firm were not required to perform an evaluation of our internal control over financial reporting as of December 31, 2023 in accordance with the provisions of the Sarbanes-Oxley Act. Accordingly, we cannot assure you that we have identified all, or that we will not in the future have additional, material weaknesses. Material weaknesses may still exist when we report on the effectiveness of our internal control over financial reporting as required by reporting requirements under Section 404.

Implementing any appropriate changes to our internal controls may distract our officers and employees, entail substantial costs to modify our existing processes and take significant time to complete. These changes may not, however, be effective in maintaining the adequacy of our internal controls, and any failure to maintain that adequacy, or consequent inability to produce accurate financial statements on a timely basis, could increase our operating costs and harm our business. In addition, investors’ perceptions that our internal controls are inadequate or that we are unable to produce accurate financial statements on a timely basis may harm our stock price and make it more difficult for us to effectively market and sell our products and services to new and existing customers.

However, if we identify future deficiencies in our internal control over financial reporting or if we are unable to comply with the demands that are placed upon us as a public company, including the requirements of Section 404 of the Sarbanes-Oxley Act, in a timely or effective manner, we may be unable to accurately report our financial results, or report them within the timeframes required by the SEC. We also could become subject to sanctions or investigations by the SEC or other regulatory authorities. In addition, if we are unable to assert that our internal control over financial reporting is effective, or if our independent registered public accounting firm is unable to express an opinion as to the effectiveness of our internal control over financial reporting when required, investors may lose confidence in the accuracy and completeness of our financial reports, we may face restricted access to the capital markets and our stock price may be adversely affected.

Our current controls and any new controls that we develop may also become inadequate because of poor design or changes in our business, including increased complexity resulting from any international expansion, and weaknesses in our disclosure controls and internal control over financial reporting may be discovered in the future. Any failure to develop or maintain effective controls or any difficulties encountered in their implementation or improvement could cause us to fail to meet our reporting obligations, result in a restatement of our financial statements for prior periods, undermine investor confidence in us and adversely affect the trading price of our common stock. In addition, if we are unable to continue to meet these requirements, we may not be able to remain listed on Nasdaq.

Changing laws and regulations could create uncertainty for Zeo regarding compliance matters and result in higher costs.

Changing laws, regulations and standards relating to corporate governance and public disclosure are creating uncertainty for public companies, increasing legal and financial compliance costs, and making some activities more time consuming. These laws, regulations and standards are subject to varying interpretations and may evolve over time as new guidance is provided by regulatory and governing bodies. This could result in continuing uncertainty regarding compliance matters and higher costs necessitated by ongoing revisions to disclosure and governance practices. We intend to invest resources to comply with evolving laws, regulations and standards, and this investment may result in increased general and administrative expenses and a diversion of management’s time and attention from revenue-generating activities to compliance activities. We cannot predict or estimate the amount or timing of additional costs it may incur to respond to these requirements. If our efforts to comply with new laws, regulations and standards differ from the activities intended by regulatory or governing bodies due to ambiguities related to their application and practice, regulatory authorities may initiate legal proceedings against us, and our business may be adversely affected.

The rules and regulations applicable to public companies make it more expensive for Zeo to obtain and maintain director and officer liability insurance, which could adversely affect its ability to attract and retain qualified officers and directors.

The rules and regulations applicable to public companies make it more expensive for Zeo to obtain and maintain director and officer liability insurance, and Zeo may be required to accept reduced coverage or incur substantially higher costs to obtain coverage. We cannot predict or estimate the amount or timing of additional costs we may incur to respond to these requirements. The potential for increased personal liability could also make it more difficult for Zeo to attract and retain qualified members of the Board, particularly to serve on its audit committee and compensation committee, and qualified executive officers.

An active, liquid market for Zeo’s securities may not develop, which would adversely affect the liquidity and price of Zeo’s securities.

The price of Zeo’s securities may vary significantly due to factors specific to Zeo as well as to general market or economic conditions. Furthermore, an active, liquid trading market for Zeo’s securities may never develop, or, if developed, it may not be sustained. You may be unable to sell your securities without depressing the market price for the securities or at all unless an active, liquid market can be established and sustained. An inactive trading market may also impair Zeo’s ability to attract and motivate employees through equity incentive awards and to acquire other companies, products or technologies by using shares of capital stock as consideration.

The market price of the shares of Class A Common Stock may decline.

The market price of the shares of Class A Common Stock may decline for a number of reasons, including if:

•        investors react negatively to the prospects of Zeo’s business;

•        Zeo’s business and prospects is not consistent with the expectations of financial or industry analysts; or

•        Zeo does not achieve the perceived benefits of the Business Combination as rapidly or to the extent anticipated by financial or industry analysts.

The price of Class A Common Stock may change significantly, even if Zeo’s business is doing well, and you could lose all or part of your investment as a result.

The trading price of shares of Class A Common Stock is likely to be volatile. The stock market recently has experienced extreme volatility. This volatility often has been unrelated or disproportionate to the operating performance of particular companies. You may not be able to resell your shares of Class A Common Stock at an attractive price due to a number of factors such as the following:

•        results of operations that vary from the expectations of securities analysts and investors;

•        results of operations that vary from those of Zeo’s competitors;

•        changes in expectations as to Zeo’s future financial performance, including financial estimates and investment recommendations by securities analysts and investors;

•        declines in the market prices of stocks generally;

•        strategic actions by Zeo or its competitors;

•        announcements by Zeo or its competitors of significant contracts, acquisitions, joint ventures, other strategic relationships or capital commitments;

•        any significant change in Zeo’s management;

•        changes in general economic or market conditions (including changes in interest rates or inflation) or trends in Zeo’s industry or markets;

•        changes in business or regulatory conditions, including new laws or regulations or new interpretations of existing laws or regulations applicable to Zeo’s business;

•        future sales of Class A Common Stock or other securities;

•        dilution as a result of future exercises of Warrants, conversion of the Convertible OpCo Preferred Units or exchanges of the Exchangeable OpCo Units;

•        investor perceptions of the investment opportunity associated with Class A Common Stock relative to other investment alternatives;

•        the public’s response to press releases or other public announcements by Zeo or third parties, including Zeo’s filings with the SEC;

•        litigation involving Zeo, Zeo’s industry, or both, or investigations by regulators into the Board, Zeo’s operations or those of Zeo’s competitors;

•        guidance, if any, that Zeo provides to the public, any changes in this guidance or Zeo’s failure to meet this guidance;

•        the development and sustainability of an active trading market for Class A Common Stock;

•        actions by institutional or activist stockholders;

•        changes in accounting standards, policies, guidelines, interpretations or principles; and

•        other events or factors, including those resulting from pandemics, natural disasters, war, acts of terrorism or responses to these events.

These broad market and industry fluctuations may adversely affect the market price of Class A Common Stock, regardless of Zeo’s actual operating performance. In addition, price volatility may be greater if the public float and trading volume of Class A Common Stock is low.

In the past, following periods of market volatility, stockholders have instituted securities class action litigation. If Zeo were involved in securities litigation, it could have a substantial cost and divert resources and the attention of executive management from Zeo’s business regardless of the outcome of such litigation.

Warrants issued in the IPO are exercisable for Class A Common Stock, which would increase the number of shares eligible for future resale in the public market and result in dilution to the stockholders of Zeo.

Outstanding Warrants to purchase an aggregate of 13,800,000 shares of Class A Common Stock are exercisable in accordance with the terms of the warrant agreement governing those securities. The exercise price of these Warrants is $11.50 per share. To the extent such Warrants are exercised, additional shares of Class A Common Stock will be issued, which will result in dilution to the then existing holders of Class A Common Stock and increase the number of shares eligible for resale in the public market.

Zeo stockholders may experience significant dilution as a result of a Convertible OpCo Preferred Unit Conversion.

Subject to the conditions described in the OpCo A&R LLC Agreement, the holder of the Convertible OpCo Preferred Units may, or OpCo may require the holder of such Convertible OpCo Preferred Units to, convert all of such holder’s Convertible OpCo Preferred Units into such number of Exchangeable OpCo Units as determined by the conversion ratio applicable to the respective Convertible OpCo Preferred Unit Conversion. Upon the occurrence of a conversion of Convertible OpCo Preferred Units into Exchangeable OpCo Units, all Exchangeable OpCo Units received as a result of such conversion shall be immediately exchanged (together with an equal number of shares of Class V Common Stock) into an equal number of shares of Class A Common Stock. Accordingly, if the Convertible OpCo Preferred Units are converted into Exchangeable OpCo Units and immediately thereafter exchanged for shares of Class A Common Stock, holders of Class A Common Stock could experience significant dilution. Further, if the holders of the shares of Class A Common Stock issued as a result of a Convertible OpCo Preferred Unit Conversion dispose of a substantial portion of such shares of Class A Common Stock in the public market, whether in a single transaction or series of transactions, it could adversely affect the market price for the Class A Common Stock. These sales, or the possibility that these sales may occur, could make it more difficult for Zeo or its stockholders to sell shares of Class A Common Stock in the future.

Zeo may be subject to securities class action litigation, which may harm its business and operating results.

Certain companies that have experienced volatility in the market price of their stock have been subject to securities class action litigation. Zeo may be the target of this type of litigation in the future. Securities litigation against Zeo could result in substantial costs and damages and divert Zeo’s management’s attention from other business concerns, which could seriously harm Zeo’s business, results of operations, financial condition or cash flows.

Zeo may also be called on to defend itself against lawsuits relating to its business operations. Some of these claims may seek significant damages amounts. Due to the inherent uncertainties of litigation, the ultimate outcome of any such proceedings cannot be accurately predicted. A future unfavorable outcome in a legal proceeding could have an adverse impact on Zeo’s business, financial condition and results of operations. In addition, current and future litigation, regardless of its merits, could result in substantial legal fees, settlements or judgment costs and a diversion of Zeo’s management’s attention and resources that are needed to successfully run Zeo’s business.

Because there are no current plans to pay cash dividends on shares of Class A Common Stock for the foreseeable future, you may not receive any return on investment unless you sell your shares of Class A Common Stock at a price greater than what you paid for them.

Zeo intends to retain future earnings, if any, for future operations, expansion (which may include potential acquisitions) and debt repayment, and there are no current plans to pay any cash dividends for the foreseeable future. The declaration, amount and payment of any future dividends on shares of Class A Common Stock will be at the sole discretion of the Board. The Board may take into account general and economic conditions, Zeo’s financial condition and results of operations, Zeo’s available cash and current and anticipated cash needs, capital requirements, contractual, legal, tax and regulatory restrictions, implications of the payment of dividends by Zeo to its stockholders or by its subsidiaries to it and such other factors as the Board may deem relevant. As a result, you may not receive any return on an investment in the shares of Class A Common Stock unless you sell such shares for a price greater than that which you paid for it.

Zeo may issue additional shares of Class A Common Stock or other equity securities without seeking approval of its stockholders, which would dilute your ownership interests and may depress the market price of Class A Common Stock.

Zeo has Warrants outstanding to purchase up to an aggregate of 13,800,800 shares of Class A Common Stock. Additionally, Zeo will issue shares of Class A Common Stock to (i) the holders of Convertible OpCo Preferred Units upon the occurrence of a Convertible OpCo Preferred Unit Conversion and (ii) the Sellers upon the conversion of Seller OpCo Units (together with an equal number of shares of Seller Class V Common Stock) into Class A Common Stock. Further, Zeo may choose to seek third-party financing to provide additional working capital for Zeo’s business, in which event Zeo may issue additional shares of Class A Common Stock or other equity securities. Zeo may also issue additional shares of Class A Common Stock or other equity securities of equal or senior rank in the future for any reason or in connection with, among other things, future acquisitions, the redemption of outstanding Warrants or repayment of outstanding indebtedness, without stockholder approval, in a number of circumstances.

The issuance of additional shares of Class A Common Stock or other equity securities of equal or senior rank would have the following effects:

•        Zeo’s existing stockholders’ proportionate ownership interest in Zeo will decrease;

•        the amount of cash available per share, including for payment of dividends in the future, may decrease;

•        the relative voting strength of each previously outstanding share of Class A Common Stock may be diminished; and

•        the market price of the shares of Class A Common Stock may decline.

If securities or industry analysts do not publish research or reports about Zeo’s business, if they change their recommendations regarding the shares of Class A Common Stock or if Zeo’s operating results do not meet their expectations, the price and trading volume of shares of Class A Common Stock could decline.

The trading market for shares of Class A Common Stock will depend in part on the research and reports that securities or industry analysts publish about Zeo or its businesses. If no securities or industry analysts commence coverage of Zeo, the trading price for shares of Class A Common Stock could be negatively impacted. In the event securities or industry analysts initiate coverage, if one or more of the analysts who cover Zeo downgrade its securities or publish unfavorable research about its businesses, or if Zeo’s operating results do not meet analyst expectations, the trading price of shares of Class A Common Stock would likely decline. If one or more of these analysts cease coverage of Zeo or fail to publish reports on Zeo regularly, demand for shares of Class A Common Stock could decrease, which might cause the share price and trading volume to decline. Accordingly, holders of Class A Common Stock may experience a loss as a result of a decline in the market price of Class A Common Stock. In addition, a decline in the market price of Class A Common Stock could adversely affect Zeo’s ability to issue additional securities and to obtain additional financing in the future.

The ability of Zeo’s management to require holders of Warrants to exercise such Warrants on a cashless basis will cause holders to receive fewer shares of Class A Common Stock upon their exercise of such Warrants than they would have received had they been able to exercise such Warrants for cash.

If Zeo calls the Warrants for redemption after the redemption criteria have been satisfied, Zeo’s management will have the option to require any holder that wishes to exercise Warrants to do so on a “cashless basis.” If Zeo’s management chooses to require holders to exercise their Warrants on a cashless basis, the number of shares of Class A Common Stock received by a holder upon exercise will be fewer than it would have been had such holder exercised his, her or its Warrants for cash. This will have the effect of reducing the potential “upside” of the holder’s investment in Zeo.

Zeo may redeem unexpired Warrants prior to their exercise at a time that is disadvantageous for holders of Warrants.

Zeo will have the ability to redeem outstanding Warrants at any time after they become exercisable and prior to their expiration, at a price of $0.01 per Warrant; provided, that the last reported sales price of shares of Class A Common Stock equals or exceeds $18.00 per share for any 20 trading days within a 30 trading-day period ending on the third business day prior to the date Zeo sends the notice of redemption to the holders of Warrants. If and when the Warrants become redeemable by Zeo, Zeo may exercise its redemption right if there is a current registration statement in

USE OF PROCEEDS

All of the shares of Class A Common Stock offered by the selling securityholders will be sold by them for their respective accounts. We will not receive any of the proceeds from these sales. The selling securityholders will pay any underwriting fees, discounts, selling commissions, stock transfer taxes, and certain legal expenses incurred by such selling securityholders in disposing of their shares of Class A Common Stock, and we will bear all other costs, fees, and expenses incurred in effecting the registration of such securities covered by this prospectus, including, without limitation, all registration and filing fees, Nasdaq listing fees, and fees and expenses of our counsel and our independent registered public accountants.

We will receive up to an aggregate of approximately $158,700,000 from the exercise of all of the Warrants assuming the exercise in full of all such Warrants for cash. Our warrants are currently “out-of-the money,” which means that the trading price of the shares of our Common Stock underlying our Warrants is below the $11.50 exercise prices, as applicable (subject to adjustment as described herein), of the Warrants. For so long as the Warrants remain “out-of-the money,” we do not expect Warrant holders to exercise their Warrants and, therefore, we do not expect to receive cash proceeds from any such exercise.

Unless we inform you otherwise in a prospectus supplement or free writing prospectus, we intend to use the net proceeds from the exercise of such Warrants for general corporate purposes.

DETERMINATION OF OFFERING PRICE

We cannot currently determine the price or prices at which shares of Class A Common Stock may be sold by the selling securityholders under this prospectus.

MARKET INFORMATION FOR COMMON STOCK AND DIVIDEND POLICY

Market Information

Our Class A Common Stock and Warrants are currently listed on Nasdaq under the symbols “ZEO” and “ZEOWW”, respectively. As of April 16, 2024, there were 23 holders of record of our Class A Common Stock and one holder of record of our Warrants. The actual number of holders of our Class A Common Stock and Warrants is greater than the number of record holders and includes holders of our Class A Common Stock and Warrants whose shares of Class A Common Stock or Warrants are held in street name by brokers and other nominees.

Dividend Policy

The Company has not paid any cash dividends on its shares of its common stock to date. The payment of cash dividends in the future will be dependent upon our revenues and earnings, if any, capital requirements and general financial condition. The payment of any dividends will be within the discretion of the Board.

UNAUDITED PRO FORMA CONDENSED COMBINED FINANCIAL INFORMATION

Introduction

The following unaudited pro forma condensed combined financial information presents the combination of financial information of ESGEN and Sunergy, adjusted to give effect to the Business Combination and related transactions. The following unaudited pro forma condensed combined financial information has been prepared in accordance with Article 11 of Regulation S-X as amended by the final rule, Release No. 33-10786 “Amendments to Financial Disclosures about Acquired and Disposed Businesses” to depict the accounting for the transaction (“Transaction Accounting Adjustments”) and present the reasonably estimable synergies and other transaction effects that have occurred or are reasonably expected to occur (“Management’s Adjustments”). ESGEN has elected not to present Management’s Adjustments and will only be presenting Transaction Accounting Adjustments in the unaudited pro forma condensed combined financial information.

The following unaudited pro forma condensed combined balance sheet as of December 31, 2023, assumes that the Business Combination occurred December 31, 2023. The following unaudited pro forma condensed combined statement of operations for the year ended December 31, 2023, presents pro forma effect to the Business Combination as if it had occurred on January 1, 2023.

The unaudited pro forma condensed combined financial statements have been presented for illustrative purposes only and do not necessarily reflect what the combined Company’s financial condition or results of operations would have been had the acquisition occurred on the dates indicated. Further, the pro forma condensed combined financial information also may not be useful in predicting the future financial condition and results of operations of the combined Company. The actual financial position and results of operations may differ significantly from the pro forma amounts reflected herein due to a variety of factors.

The unaudited pro forma condensed combined balance sheet as of December 31, 2023, has been derived from:

•        The historical audited financial statements of ESGEN as of December 31, 2023; and

•        The historical audited financial statements of Sunergy as of December 31, 2023.

The unaudited pro forma condensed combined statement of operations for the year ended December 31, 2023, has been derived from:

•        The historical audited financial statements of ESGEN for the year ended December 31, 2023; and

•        The historical audited financial statements of Sunergy for the year ended December 31, 2023.

The following unaudited pro forma condensed combined financial information has been prepared in accordance with Article 11 of Regulation S-X as in effect on the date hereof which incorporates Transaction Accounting Adjustments. Sunergy and ESGEN have elected not to present any estimates related to potential synergies and other transaction effects that are reasonably expected to occur or have already occurred and will only be presenting Transaction Accounting Adjustments in the unaudited pro forma condensed combined financial information.

This information should be read together with the financial statements and related notes, as applicable, of each of Sunergy and ESGEN included herein and in the Current Report on Form 8-K filed by the registrant on March 20, 2024.

Description of the Transactions

Business Combination

On March 13, 2024, the registrant consummated its previously announced business combination, pursuant to the Business Combination Agreement. Prior to the Closing, (i) except as otherwise specified in the Business Combination Agreement, each issued and outstanding Class B ordinary share of ESGEN was converted into one ESGEN Class A Ordinary Share; and (ii) ESGEN was domesticated into the State of Delaware so as to become a Delaware corporation. In connection with the Closing, the registrant changed its name from “ESGEN Acquisition Corporation” to “Zeo Energy Corp.”

Conversion of Securities and Transaction Consideration

Upon the Domestication, each then-outstanding ESGEN Class A Ordinary Share was cancelled and converted into one share of Zeo Class A Common Stock, and each then-outstanding ESGEN Public Warrant was assumed and converted automatically into a warrant of the registrant, exercisable for one share of Zeo Class A Common Stock. Additionally, each outstanding unit of ESGEN was cancelled and converted into one share of Zeo Class A Common Stock and one-half of one warrant of the registrant.

In accordance with the terms of the Business Combination Agreement, Sunergy caused all holders of Sunergy Convertible Interests existing immediately prior to the Closing to either exchange or convert all such holder’s Sunergy Convertible Interests into Sunergy Company Interests in accordance with the governing documents of Sunergy or the Sunergy Convertible Interests.

At the Closing, ESGEN contributed to OpCo (1) all of its assets (excluding its interests in OpCo, but including the amount of cash in the Trust Account as of immediately prior to the Closing (after giving effect to the exercise of redemption rights by ESGEN shareholders)), and (2) a number of newly issued shares of Zeo Class V Common Stock equal to the number of Seller OpCo Units (as defined in the Business Combination Agreement) and (y) in exchange, OpCo issued to ESGEN (i) a number of Class A common units of OpCo which equaled the number of total shares of Zeo Class A Common Stock issued and outstanding immediately after the Closing and (ii) a number of warrants to purchase OpCo Manager Units which equaled the number of Warrants issued and outstanding immediately after the Closing. Immediately following the ESGEN Contribution, (x) the Sellers contributed to OpCo the Sunergy Company Interests and (y) in exchange therefor, OpCo transferred to the Sellers the Seller OpCo Units and the Seller Class V Shares.

Prior to the Closing, Sellers transferred 24.167% of their Sunergy Company Interests (which were thereafter exchanged for Seller OpCo Units and Seller Class V Shares at the Closing, as described above) pro rata to Sun Managers, in exchange for Class A Units (as defined in the SM LLCA) in Sun Managers. In connection with such transfer, Sun Managers executed a joinder to, and became a “Seller” for purposes of, the Business Combination Agreement. Sun Managers intends to grant Class B Units (as defined in the SM LLCA) in Sun Managers through the Management Incentive Plan adopted by Sun Managers to certain eligible employees or service providers of OpCo, Sunergy or their subsidiaries, in the discretion of Timothy Bridgewater, as manager of Sun Managers. Such Class B Units may be subject to a vesting schedule, and once such Class B Units become vested, there may be an exchange opportunity through which the grantees may request (subject to the terms of the Management Incentive Plan and the OpCo A&R LLC Agreement) the exchange of their Class B Units into Seller OpCo Units (together with an equal number of Seller Class V Shares), which may then be converted into Zeo Class A Common Stock (subject to the terms of the Management Incentive Plan and the OpCo A&R LLC Agreement). Grants under the Management Incentive Plan will be made after Closing.

As of the Closing Date, upon consummation of the Business Combination, the only outstanding shares of capital stock of the registrant were shares of Zeo Class A Common Stock and Zeo Class V Common Stock.

The material terms and conditions of the Business Combination Agreement are described in greater detail in the Company’s definitive proxy statement/prospectus filed with the SEC pursuant to Rule 424(b)(3) under the Securities Act, on February 13, 2024, in the section entitled “The Business Combination Agreement” beginning on page 146, which information is incorporated herein by reference.

Related Agreements

Sponsor PIPE Investment

In connection with entering into the Business Combination Agreement, ESGEN and the Sponsor entered into the Sponsor Subscription Agreement, pursuant to which, among other things, the Sponsor agreed to purchase an aggregate of 1,000,000 Convertible OpCo Preferred Units (and be issued an equal number of shares of Zeo Class V Common Stock concurrently with the Closing at a cash purchase price of $10.00 per unit and up to an additional 500,000 Convertible OpCo Preferred Units (together with the concurrent issuance of an equal number of shares of Zeo Class V Common Stock) during the six months after Closing if called for by Zeo. Prior to the Closing, ESGEN informed the Sponsor that it wished to call for the additional 500,000 Convertible OpCo Preferred Units at the Closing and, as a result, a total of 1,500,000 Convertible OpCo Preferred Units were issued to Sponsor in return for aggregate consideration of $15,000,000.

Amendments to the Letter Agreement

Concurrently with the execution of the Business Combination Agreement, on April 19, 2023, the Initial Shareholders entered into the Letter Agreement Amendment, pursuant to which, among other things, (i) the Initial Shareholders agreed not to transfer his, her or its ESGEN Class B ordinary shares (or the Zeo Class A Common Stock ultimately issuable in exchange for such ESGEN Class B ordinary shares pursuant to the Business Combination Agreement) prior to the earlier of (a) six months after the Closing or (b) subsequent to the Closing (A) if the last sale price of the Zeo Class A Common Stock quoted on Nasdaq is greater than or equal to $12 per share (as adjusted for stock splits, stock dividends, reorganizations, recapitalizations and the like) for any 20 trading days within a 30-consecutive trading day period commencing at least 90 days after Closing, or (B) the date on which Zeo completes a liquidation, merger, share exchange or other similar transaction that results in all of Zeo’s stockholders having the right to exchange their Zeo Class A Common Stock for cash, securities or other property, (ii) the Initial Shareholders agreed to waive any adjustment to the conversion ratio set forth in the governing documents of ESGEN with respect to the ESGEN Class B ordinary shares prior to the earlier of the ESGEN Share Conversion or the Closing, (iii) the Sponsor agreed to irrevocably surrender and forfeit 2,361,641 ESGEN ordinary shares, (iv) the Initial Shareholders other than Sponsor agreed to irrevocably surrender and forfeit 538,359 ESGEN ordinary shares, (v) the Initial Shareholders and Sponsor agreed to forfeit an additional 500,000 shares of Zeo Class A Common Stock if, within two years of Closing, the Convertible OpCo Preferred Units are redeemed or converted (with such shares subject to a lock-up for two years after Closing) and (vi) the Initial Shareholders agreed to forfeit all of their SPAC Private Warrants (as defined in the Business Combination Agreement) in connection with Closing.

Side Letter

In connection with the Closing, ESGEN, the Sponsor, the Initial Shareholders and Sunergy entered into a side letter, pursuant to which 778,381 of the Sponsor Forfeited Shares were retained in the treasury of Zeo rather than being cancelled and such shares, following conversion into shares of Zeo Class A Common Stock, were available to be issued in connection with the Closing. At the Closing these shares were issued to K2 (as defined below), Piper (as defined below) and three other third-party investors.

NRA Agreement

On March 11, 2024, ESGEN entered into a non-redemption agreement (the “NRA”) with The K2 Principal Fund L.P. (“K2”), pursuant to which K2 agreed (i) to purchase at least 174,826 ESGEN Class A Ordinary Shares in the open market from investors who had elected to redeem such shares in connection with ESGEN’s extraordinary general meeting of shareholders held to approve the transactions contemplated by the Business Combination Agreement and (ii) not to redeem and to validly rescind any redemption requests on such purchased ESGEN Class A Ordinary Shares. K2 ultimately purchased 176,786 ESGEN Class A Ordinary Shares in accordance with the foregoing.

In exchange for the foregoing commitments to purchase and not redeem such Class A Ordinary Shares, ESGEN agreed to issue, for no consideration an aggregate of 225,174 shares of Zeo Class A Common Stock at the Closing.

Engagement Letter

On April 19, 2023, Piper Sandler & Co. (“Piper”) and Sunergy agreed to the withdrawal of Piper from its role as financial advisor to Sunergy with respect to the Business Combination, and on September 5, 2023, Piper changed its role to providing buy-side and debt advisory services to Sunergy pursuant to an amendment to its engagement letter with Sunergy. On March 8, 2024, Piper and Sunergy agreed to a second amendment to the engagement letter (as so amended, the “Engagement Letter”) which provided that (i) if the Closing occurred, Piper would be issued 50,000 shares of Zeo Class A Common Stock at the Closing (and be added as a party to the A&R Registration Rights Agreement) and be paid six equal installments of $500,000, to be paid every three months starting on July 15, 2024 in full satisfaction of amounts due pursuant to the Engagement Letter and (ii) subject to certain conditions, Piper was granted a right of first refusal on financial advisory services for a period of eighteen months following Closing. Accordingly, Zeo issued Piper 50,000 shares of Zeo Class A Common Stock at Closing.

A&R Registration Rights Agreement

On March 13, 2024, the Sellers, the Initial Shareholders, Piper (the “New PubCo Holders”) and Zeo entered into the A&R Registration Rights Agreement, pursuant to which, among other things, Zeo agreed to provide the New PubCo Holders certain registration rights with respect to certain shares of Zeo Class A Common Stock held by them or otherwise issuable to them pursuant to the Business Combination Agreement, the OpCo A&R LLC Agreement or the Charter.

OpCo A&R LLC Agreement

Following the Business Combination, Zeo has been organized in an “Up-C” structure, such that OpCo and the subsidiaries of OpCo hold and operate substantially all of the assets and business of Zeo, and Zeo is a publicly listed holding company that holds common equity interests in OpCo, which holds all of the equity interests in Sunergy. Until any redemption of Exchangeable OpCo Units has occurred as described below, the Sellers generally hold the remainder of the common equity interests of OpCo through their ownership of the Exchangeable OpCo Units. In addition, as described above, the Sponsor owns all of the Convertible OpCo Preferred Units upon the Closing. Except for the consent rights of Sponsor noted below or as specifically set forth in the OpCo A&R LLC Agreement, Zeo has the full, exclusive and complete discretion to manage and control the business and affairs of OpCo.

Accordingly, on March 13, 2024, concurrently with the Closing, OpCo amended and restated its limited liability company agreement in its entirely to, among other things, provide a holder of Exchangeable OpCo Units the right to cause OpCo to redeem one or more of such Exchangeable OpCo Units, together with the cancellation of an equal number of shares of such holder’s Zeo Class V Common Stock, for shares of Zeo Class A Common Stock on a one-for-one basis, or, at the election of Zeo (as manager of OpCo), cash, in each case, subject to certain restrictions set forth in the OpCo A&R LLC Agreement and the Charter. The OpCo A&R LLC Agreement also provides for mandatory OpCo Unit Redemptions in certain limited circumstances, including in connection with certain changes of control. Subject to certain conditions, the Convertible OpCo Preferred Units are redeemable by Zeo and following the first anniversary of the Closing may be converted by the Sponsor into Exchangeable OpCo Units (and then would be immediately converted, together with the accompanying shares of Zeo Class V Common Stock, into Zeo Class A Common Stock). The Convertible OpCo Preferred Units have accruing distributions of 10% per annum and the Sponsor as holder thereof has certain consent rights over the taking of certain actions of OpCo and its subsidiaries.

The following table summarizes the pro forma number of shares of Zeo Common Stock outstanding following the consummation of the Business Combination and the Domestication, discussed further in the sections below, excluding the potential dilutive effect of the Warrants and the Convertible OpCo Preferred Units.

The following table shows the book equity per share of Zeo Common Stock held by non-redeeming holders of Zeo Common Stock:

UNAUDITED PRO FORMA CONDENSED COMBINED BALANCE SHEET

AS OF DECEMBER 31, 2023(1)

UNAUDITED PRO FORMA CONDENSED COMBINED BALANCE SHEET

AS OF DECEMBER 31, 2023(1) — (Continued)

____________

(1)      The unaudited pro forma condensed combined balance sheet as of December 31, 2023, combines the audited balance sheet of Sunergy as of December 31, 2023, with the audited balance sheet of ESGEN as of December 31, 2023.

UNAUDITED PRO FORMA CONDENSED COMBINED STATEMENT OF OPERATIONS

FOR THE YEAR ENDED DECEMBER 31, 2023(2)

____________

(1)      Please refer to Note 7 (“Net Loss per Share”) for details.

(2)      The unaudited pro forma condensed combined statement of operations for the year ended December 31, 2023, combines the audited statement of operations of Sunergy for year ended December 31, 2023, with the audited statement of operations of ESGEN for the year ended December 31, 2023.

NOTES TO UNAUDITED PRO FORMA CONDENSED COMBINED FINANCIAL STATEMENTS

Note 1 — Basis of Presentation and Accounting Policies

The Business Combination was accounted for as a reverse recapitalization in accordance with GAAP as Sunergy was determined to be the accounting acquirer, primarily due to the fact that Sunergy stockholders continue to control the combined Company. Under this method of accounting, although ESGEN acquired all of the outstanding equity interests of Sunergy in the Business Combination, ESGEN was treated as the “acquired” company for financial reporting purposes. Accordingly, the Business Combination was treated as the equivalent of Sunergy issuing equity for the net assets of ESGEN, accompanied by a recapitalization. The net assets of ESGEN were stated at historical cost, with no goodwill or other intangible assets recorded. Operations prior to the Business Combination were those of Sunergy.

The unaudited pro forma condensed combined balance sheet as of December 31, 2023 assumes that the Business Combination and related transactions occurred on December 31, 2023. The unaudited pro forma condensed combined statements of operations for the year ended December 31, 2023 presents pro forma effect to the Business Combination as if it had been completed on January 1, 2023.

The unaudited pro forma condensed combined balance sheet as of December 31, 2023 has been prepared using, and should be read in conjunction with, the following:

•        ESGEN’s audited balance sheet as of December 31, 2023; and

•        Sunergy’s audited consolidated balance sheet as of December 31, 2023.

The unaudited pro forma condensed combined statement of operations for the year ended December 31, 2023 has been prepared using, and should be read in conjunction with, the following:

•        ESGEN’s audited statement of operations for the year ended December 31, 2023; and

•        Sunergy’s audited consolidated statement of operations for the year ended December 31, 2023.

As the unaudited pro forma condensed combined financial information has been prepared based on these preliminary estimates, the final amounts recorded may differ materially from the information presented.

The historical financial statements of Sunergy have been prepared in accordance with U.S. GAAP. The historical financial statements of ESGEN have been prepared in accordance with U.S. GAAP. The unaudited pro forma condensed combined financial information reflects U.S. GAAP, the basis of accounting used by Sunergy.

The pro forma adjustments reflect adjustments to record the tax receivable agreement liability. Upon the completion of the Business Combination, PubCo will be a party to a tax receivable agreement. Under the terms of that agreement 85% of the tax benefit to PubCo represents additional purchase price. The tax impacts of the transaction were estimated based on the applicable law and expected filing jurisdictions in effect on December 31, 2023.

The realizability of the deferred tax assets is subject to various estimates and assumptions, including preliminary projections of future taxable income of appropriate character. Therefore, the recognition of deferred tax assets, including any valuation allowances, and the resulting impact on the tax receivable agreement liability is subject to change based on a final analysis upon completion of the transaction. The pro forma reflects adjustments to deferred tax assets to reflect the difference between the financial statement and tax basis in the investment in Sunergy. The realizability of the deferred tax assets is subject to various estimates and assumptions, including preliminary projections of future taxable income of appropriate character. Therefore, the recognition of deferred tax assets, including any valuation allowance, and the resulting impact on the tax receivable agreement liability is subject to change based on a final analysis upon completion of the transaction.

The share amounts and ownership percentages set forth above are not indicative of voting percentages and do not take into account ESGEN Warrants that will remain outstanding immediately following the Business Combination and may be exercised thereafter.

Upon consummation of the Business Combination, management has performed a comprehensive review of the two entities’ accounting policies. As a result of the review, management has not identified differences between the accounting policies of the two entities which have a material impact on the financial statements of the combined Company. Based on its analysis, management did not identify any differences that would have a material impact on the unaudited pro forma condensed combined financial information. As a result, the unaudited pro forma condensed combined financial information does not assume any differences in accounting policies.

Note 2 — Adjustments to Unaudited Pro Forma Condensed Combined Financial Information

The unaudited pro forma condensed combined financial information has been prepared to illustrate the effect of the Business Combination and has been prepared for informational purposes only.

The following unaudited pro forma condensed combined financial information has been prepared in accordance with Article 11 of Regulation S-X as amended by the final rule, Release No. 33-10786 “Amendments to Financial Disclosures about Acquired and Disposed Businesses” to depict the accounting for the transaction (“Transaction Accounting Adjustments”) and present the reasonably estimable synergies and other transaction effects that have occurred or are reasonably expected to occur (“Management’s Adjustments”). EFHAC has elected not to present Management’s Adjustments and is only presenting Transaction Accounting Adjustments in the unaudited pro forma condensed combined financial information. The historical financial statements have been adjusted in the unaudited pro forma condensed combined financial information to include all necessary Transaction Accounting Adjustments pursuant to Article 11 of Regulation S-X, including those that are not expected to have a continuing impact.

The audited historical financial statements have been adjusted in the unaudited pro forma condensed combined financial information to give pro forma effect to transaction accounting adjustments that reflect the accounting for the transaction under GAAP. Sunergy and ESGEN have not had any historical relationship prior to the Business Combination. Accordingly, no pro forma adjustments were required to eliminate activities between the companies.

The pro forma basic and diluted earnings per share amounts presented in the unaudited pro forma condensed combined statement of operations are based upon the number of the combined Company’s shares outstanding, assuming the Business Combination occurred on January 1, 2023.

Transaction Accounting Adjustments to Unaudited Pro Forma Condensed Combined Balance Sheet

The Transaction Accounting Adjustments to the unaudited pro forma condensed combined balance sheet as of December 31, 2023, are as follows:

A.     Reflects the proceeds of $15,000,000 received from the initial draw of the Convertible Preferred Equity Security and the issuance of 1,500,000 Class V shares to the Sponsor.

B.      Reflects the liquidation and reclassification of $0.3 million of funds held in the Trust Account to cash that became available following the Business Combination.

C.     Reflects the payments of $1.0 of Business Combination related fees and expenses of Sunergy post December 31, 2023 and pre-closing of the Business Combination, the payment of $7.0 million of ESGN Business Combination related fees and expenses at the closing of the Business Combination, and to accrue $0.7 million of ESGEN Business Combination related fees and expenses and $1.8 million of Sunergy Business Combination related fees and expenses to be paid post-closing of the Business Combination.

D.     Represents the exchange of outstanding Sunergy units into 33,730,000 shares of Class V common stock at a par value of $0.0001 per share at the Business Combination.

E.      Represents the elimination of ESGEN’s historical accumulated losses after recording the transaction costs to be incurred by ESGEN as described in (C) above, the recording of interest earned in the Trust and the administrative fee due to related party as described in (I) below, the recording of the accretion of ordinary shares subject to redemption as described in (H) below, recording of the stock based compensation as described in (M) below, the recording of the cancellation of ESGEN private warrants as described in (N) below and the recording of the shares issued to K2 as described in (Q) below.

F.      Reflects the reclassification of 248,579 shares of ESGEN ordinary shares subject to possible redemption to permanent equity.

G.     Reflects the forfeiture of 2,900,000 shares of ESGEN Class B ordinary shares and the conversion of the remaining ESGEN Class B ordinary shares into Class A ordinary shares on a one-for-one basis.

H.     Reflects the extension payments and interest earned in the Trust account subsequent to December 31, 2023 and to record the accretion of the ordinary shares subject to redemption.

I.       Reflects the additional draw of $0.1 million on the ESGEN October 2023 promissory note — related party, the $0.5 million draw on the ESGEN January 2024 promissory note — related party, and $0.2 million due to related party subsequent to December 31, 2023.

J.       Reflects the recognition of the non-controlling interest as a result of the Up-C structure. In accordance with ASC 480-10-S99 the non-controlling interest is classified as mezzanine equity as the units of the non-controlling interest are exchangeable for Class A Shares at ESGEN Acquisition Corp. (and surrender of the Class V share) or for a cash payment equal to the product of (x) the number of shares of Class A Common Stock that would be delivered to a Member in an Exchange if such Exchange were to be settled in shares of Class A Common Stock, multiplied by (y) the price per share of Class A Common Stock. The cash payment is at the discretion of the Manager (i.e. ESGEN Acquisition Corp.). However, in an Exchange of Class B Units, the price per share of Class A Common Stock shall only be determined by an underwritten offering undertaken by the Manager in anticipation of the Exchange (a “Liquidity Offering”).

K.     Reflects the adjustments to deferred tax assets to reflect the difference between the financial statement and tax basis in the investment in Sunergy and includes tax benefit related to future deductibility of ESGEN legal accruals. The adjustment is net of a valuation allowance related to outside basis in the investment of Sunergy that is capital in nature and is not believed to be realized in the foreseeable future.

L.      Reflects the redemption of 1,159,976 ESGEN Class A ordinary shares at a redemption price of $11.50 per share for an aggregate amount of approximately $13,336,056 on March 12, 2024.

M.     Reflects the recognition of stock-based compensation at the consummation of the Business Combination related to the ESGEN Class B Founders Shares transferred to independent directors.

N.     Reflects the cancellation of 14,040,000 ESGEN private placement warrants at the Business Combination.

O.     Reflects the forgiveness of $0.3 million of ESGEN due to related party, $1.9 million of ESGN promissory note — related party and the payment of $0.5 million of the ESGEN promissory note issued in January 2024 at the closing of the Business Combination.

P.       Reflects the issuance of 553,207 shares of Class A common stock, par value $0.0001, at $5 per share to K2, Piper and three other third party advisors for services rendered in connection with the Business Combination.

Q.     Reflects the issuance of 225,174 shares of Class A common stock, par value $0.0001, at $6.97 per share, the closing price of Zeo Class A common stock on the day of the closing of the Business Combination, issued to K2 pursuant to the terms of the Non-Redemption Agreement.

R.     Reflects the Domestication by converting each outstanding ESGEN Class A ordinary share into Class A common stock of Zeo, par value $0.0001 per share, on a one-for-one basis.

Transaction Accounting Adjustments to Unaudited Pro Forma Condensed Combined Statements of Operations

The Transaction Accounting Adjustments included in the unaudited pro forma condensed combined statement of operations for year ended December 31, 2023 are as follows:

AA.  Reflects the elimination of interest income generated from the investments held in the Trust Account after giving effect to the Business Combination as if it had occurred on January 1, 2023.

BB.   To eliminate the administrative service fees that will be ceased to pay upon closing of the Business Combination.

CC.   Reflects the transaction costs of ESGEN.

DD.   Reflects the recognition of net income attributable to non-controlling interest as a result of the Up-C structure.

EE.   Reflects the pro forma federal and state income tax due at PubCo (consolidated).

FF.    Reflects the recognition of stock-based compensation at the consummation of the Business Combination related to the ESGEN Class B Founders Shares that were transferred to independent directors.

GG.  Reflects the reversal of the fair value adjustment due to the cancellation of the 14,040,000 ESGEN private placement warrants.

HH.  Reflects the expense related to the issuance of 553,207 shares of Class A common stock, par value $0.0001, at $5 per share to K2, Piper and three other third party advisors for services rendered in connection with the Business Combination.

II.     Reflects expense related to the issuance of 225,174 shares of Class A common stock, par value $0.0001, at $6.97 per share, the closing price of Zeo Class A common stock on the day of the closing of the Business Combination, issued to K2 pursuant to the terms of the Non-Redemption Agreement.

Note 3 — Net Loss per Share

Represents the loss per share calculated using the historical weighted average shares outstanding, and the issuance of additional shares in connection with the Business Combination, assuming the shares were outstanding since January 1, 2023. As the Business Combination is being reflected as if it had occurred at the beginning of the period presented, the calculation of weighted average shares outstanding for basic and diluted loss per share assumes that the shares issued in connection with the Business Combination have been outstanding for the entire period presented.

The unaudited pro forma condensed combined financial information has been prepared with the actual redemptions of Public Shares by ESGEN’s Public Shareholders for the year ended December 31, 2023:

____________

(1)      The potentially dilutive outstanding securities were excluded from the computation of pro forma net loss per share, basic and diluted, because their effect would have been anti-dilutive.

(2)      Assumes the conversion of $15,000,000 of the Convertible Preferred equity security at a conversion price of $11.00 per share.

BUSINESS

Mission

Our company and personnel are passionate about delivering cost savings and increased independence and reliability to energy consumers. Our mission is to expedite the country’s transition to renewable energy by offering our customers an affordable and sustainable means of achieving energy independence.

Business Overview

We were originally incorporated under the name “ESGEN Acquisition Corp.” as a blank check company incorporated as a Cayman Islands exempted company and formed for the purpose of effecting a merger, share exchange, asset acquisition, share purchase, reorganization, or similar business combination with one or more businesses. As discussed in this prospectus, we completed the Business Combination with Sunergy on March 13, 2024 and changed our name to “Zeo Energy Corp.”

Sunergy was created through the Contribution of Sunergy Solar and Sun First Energy to Sunergy on October 1, 2021. Sunergy Solar, formed in 2005, and initially focused on providing heating, ventilation and air conditioning products and services in Florida, later expanded into installing residential solar energy systems sold directly by the company and third-party sales dealerships. Sun First Energy was established in 2019, and, from its formation to the date of the Contribution, it sold residential solar energy systems in Florida that were installed by other companies. Prior to the Contribution, Sunergy Solar and Sun First Energy had collaborated on residential solar energy system installations and shared a commitment to quality, integrity and customer satisfaction. The Contribution established a vertically integrated company offering solutions that included sale, provision, installation, operation and maintenance of residential solar energy systems and other energy efficient equipment of services. Many of our solar energy system customers also purchase other energy efficiency-related equipment or services or roofing services from us.

We are a vertically integrated provider of residential solar energy systems, other energy efficient equipment and related services currently serving customers in Florida, Texas, Arkansas and Missouri.

Since the Contribution, we have expanded operations by increasing the number of installations, sales, and administration personnel from approximately 180 as of the Contribution to approximately 288 as of December 31, 2023. In January 2022, we began selling and installing residential solar energy systems and other energy efficiency-related equipment in Texas, in January 2023, we expanded into Arkansas, and, in September 2023, we entered Missouri.

Products and Services

Residential Solar Energy Systems

Zeo’s primary business activity is selling and installing residential solar energy systems that homeowners use to supplement the amount of usable electricity required to power their homes. We currently operate in Florida, Texas, Arkansas and Missouri, and have experienced rapid growth in our business since 2020.

Other Energy Efficient Equipment and Services

In 2023, approximately 23% of our customers purchased one or more insulation services, such as adding insulation to a home’s attic or walls. In 2023, in approximately 53% of our sales our customers purchased adders that consisted of equipment designed to increase energy efficiency, including items such as hybrid electric water heaters or swimming pool pumps. During 2023, 1% of our customers purchased battery-based energy storage systems. These battery-based energy storage systems store energy generated from their residential solar energy systems to be used when the system generates less usable electricity than the home requires (such as at night or on cloudy days).

Roofing Services

We install roofs in Florida, where our subsidiary, Sunergy Roofing & Construction, Inc., is a licensed roofing contractor. In Texas and Arkansas, for some solar energy system customers that need roofing services, we contract with roofing companies for the services. We plan to continue growing our roofing operations, as we believe our roofing services complement our residential solar energy systems and for some customers helps to expedite solar system installations.

Subcontractors

We use subcontractors to install some of our residential solar energy systems at times when we do not have a sufficient number of our own installation teams to timely complete the project. We also use subcontractors to provide all of our insulation services and to install some of the roofing services and energy efficient equipment such as hybrid electric water heaters and pool pumps which we sell. Our subcontractor fees for residential solar energy system installations are typically based on total wattage installed, and our arrangements with installation subcontractors allow either party to terminate the agreement for convenience.

Marketing and Sales

We market our products and services to potential customers directly through in-home visits carried out by our internal sales agents and indirectly through external sales dealers. In the case of leases, a customer is approached by and communicates with the same sales personnel as if the customer were purchasing a system directly from Zeo. We also engage in digital marketing efforts on our own or through third-party marketing specialists, including search engine optimization and social media communications to strengthen our online marketing presence. Our code of conduct applies to our employees, independent contractors and dealers, and it requires adherence to high ethical standards when carrying out business activities.

Internal Direct Sales Force

We have established an internal team of sales agents that markets and sells directly to customers through door-to-door sales approaches. As of December 31, 2023 this team included approximately 270 sales agents, reflecting an approximately 100% agent increase from December 31, 2022. Our sales agents are engaged through full-time contracts lasting from April through August, which is our primary selling season. Sales made through our internal sales team have lower customer acquisition costs than sales sourced through our external dealers. In 2023, approximately 50% of the total systems we installed were sold through our internal sales team.

Sales Through External Dealers

We also install systems sold by external sales dealers that act as our sales representatives with potential customers. The number of dealers that have entered into a current arrangement to sell our solar panel systems was approximately 30 as of December 31, 2023 compared to approximately 20 as of December 31, 2022. The percentage of sales that originate with our external dealers increases during the fall and winter months when our internal sales efforts are diminished. We provide field support and training to these dealers on our sales offerings, sales processes and other business processes, including our software sales platform.

Upon our selection of and engagement with a dealer, the dealer executes our dealer agreement. The majority of our dealer agreements require the dealers to exclusively represent our business with respect to the particular products or services we sell. Dealers have the option of choosing to execute a contract that does not require this exclusivity, and some select this option. Our dealer contracts are terminable for convenience by either party. For each residential solar energy system that we install for a customer that was sold by a dealer, after we receive payment, we compensate the dealer with a commission based on the number of watts of solar panels installed.

We recruit and select dealers based on their experience in the market, ability to produce sales and general reputation for ethical behavior within the industry. As part of our dealer contract, we require our dealers to agree in writing to comply with our code of conduct when carrying out their marketing and other activities.

Customer and Leasing Agreements

A homeowner becomes our customer typically by signing a contract with us to purchase and receive installation of a solar energy system. We have also began to install solar energy systems that are leased by the customer under an agreement between the customer and a third-party leasing company under which the leasing company will own and lease to a customer a solar energy system. A customer that chooses our products and services typically signs the contract after meeting with one of our sales agents or dealers in the customer’s home and receiving a preliminary system design for their home and pricing for the system. Whether the customer determines to purchase or lease the solar energy system, the sales agent or dealer determines the pricing to be offered to the customer based on product and

services price information stored in our sales software for the system components included in a customer’s proposed system. After the customer signs the contract, we schedule and conduct a site survey. If during the site survey we discover property code compliance or other complications with the planned design and installation, we may issue a change order; if required changes represent additional costs to us or the customer, the party that would be responsible for those costs may choose to cancel the contract. After the site survey, we prepare formal design and engineering documents and apply for applicable permits from local government authorities. After required permits are obtained, we schedule and install the solar energy system and any other equipment purchased on the customer’s home.

Purchase Contract Warranties.    As the owner of the residential solar energy system under the purchase and installation agreement, customers receive a manufacturer’s limited warranty for system components. For the principal components of solar panels, inverter, and racking, the manufacturer’s limited warranty typically lasts 25 years. Manufacturers control whether the warranty periods they offer will change for equipment purchased in the future. Though we are not responsible for a manufacturer’s compliance with warranty obligations, we assist customers in contacting the manufacturer if a warranty issue arises. We provide customers at least a ten-year limited warranty for our installation work and at least a five-year limited warranty against roof penetrations. In most of our purchase and installation agreements that we used prior to 2023, we provided a 25-year limited warranty for installation work and against roof penetrations.

Purchase Contracts and Financed Sales.    For the period from January 1, 2023 through December 31, 2023, the large majority of our customers (at least 90%) who purchased residential solar energy systems from us entered into a loan arrangement with a third party to finance the purchase over an extended period of time. The loan agreement between the customer and the third-party lender typically has a repayment term of between 7 and 25 years and requires the customer to pay either a minimal or no down payment. The lender pays us our portion of the purchase payment after completion of system installation.

Purchase Contracts and Cash Sales.    For the period from January 1, 2023 through December 31, 2023, a small minority of our customers (less than 3%) have paid us in cash for the purchase of residential solar energy systems. For those sales, our purchase contract requires the customer to pay 25% of the purchase price upon execution of the purchase agreement, 50% when we begin installation, and the final 25% on the last day of installation. Installation is usually commenced and completed either in a single day or within several days.

System Leases.    In December 2022, we launched a program offering customers the option of leasing our solar energy systems from a third-party leasing company. The customer agrees to pay the leasing company a predetermined monthly fee for the electricity produced by the residential solar energy system. Though we have plans to increase the number of leased systems we install, as of December 31, 2023, 8% of the systems we have installed in 2023 are leased by the customer, though we expect that percentage to increase in 2024. The lease term between the leasing company and the customer is 25 years. The customer agrees to pay the leasing company a predetermined monthly fee for the electricity produced by the solar energy system. The monthly fee generally increases annually over the lease term at a predetermined rate, and the customer has the option to renew the lease for five to ten years. The potential advantage to the customer of a lease agreement is that a third-party owner of the residential solar energy system may take more advantage of available government tax incentives for solar energy production, which may allow them to lease the system to the customer at monthly rates that are lower for the customer than if the customer were financing its own purchase of the system. We installed the first leased solar energy system in April 2023 and, as of December 31, 2023, we have installed approximately 460 leased solar energy systems. In the lease model offered to our customers, the third-party leasing company contracts with the homeowner customer to install a solar energy system owned by the leasing company and leased to the customer. The leasing company contracts with Zeo to purchase system equipment and install the solar energy system and to maintain and service the system on the leasing company’s behalf during the life of the lease.

As of the date of this prospectus, Zeo’s customers have solely entered into leasing agreements with third-party leasing companies established and managed by White Horse Energy, LC (“White Horse Energy”), a holding company of which Mr. Bridgewater, Zeo’s Chairman, Chief Executive Officer and Chief Financial Officer is the owner and manager. Subject to investor and customer demand, White Horse Energy intends to attract more investors to form third-party leasing companies. No assurance can be given that White Horse Energy will be able to do so or that arrangements can be made with other funds to act as lessors of Zeo’s solar energy systems in the future. Zeo is exploring leasing arrangements with other third parties with an objective of offering customers a choice of purchase or lease options.

Supply

The main components of our residential solar energy systems are solar panels, inverters and racking systems. Common related components or systems that we may additionally supply are battery-based energy storage systems, insulation, hybrid electric water heaters, swimming pool pumps and roofing. All of the products that we install are manufactured by third parties. We select products and system components, suppliers and distributors based on cost, reliability, warranty coverage, performance characteristics and ease of installation, among other factors.

While we procure products and components from multiple suppliers and distributors to reduce the likelihood that we experience an inability to procure those products and components, the primary supplier from which we purchase the equipment that we install is Greentech. Greentech also provides us inventory management services by holding equipment in its inventory until it delivers directly to the customer site for installation. We purchase from Greentech through a credit agreement under which Greentech extends us credit for purchases, and we are obligated to make payments by the 15th day of the month following each purchase. A purchase discount is available for early cash payment, and a service charge of 1.5% per month can be assessed for payments made more than 30 days after the invoice date. Our agreement with Greentech does not require either party to continue to conduct new business with the other party. During 2023, we purchased approximately 98% of the equipment that we installed through Greentech. We believe our relationship with Greentech, and the volume of business we do through them, has established us as a preferred customer and enables us to procure components at attractive terms. If our relationship with Greentech were to be terminated, there are other distributors of the same or similar equipment, and we believe we could readily obtain supplies from those other distributors, though they may take some time to develop the efficient logistics system Greentech employs now on our behalf delivering products to the customer installation sites.

Heightened inflation in the costs of labor and components beginning in 2020 and continuing today has contributed to fluctuating prices for solar energy equipment. At times, we have had to pay increased prices to obtain equipment. This has not yet prevented us from obtaining the products we need to install systems purchased by our customers, but there can be no assurance that this will continue. We do not have information that allows us to quantify the specific amount of cost increases attributable to inflationary pressures.

We have previously experienced price increases and temporary supply delays resulting from multiple market phenomena, including the COVID-19 pandemic. The majority of the solar panels and other equipment that we install are manufactured outside of the U.S., and most are manufactured in China. The general supply chain issues resulting from the COVID-19 pandemic have had specific impacts on our sources of supply for solar energy equipment. These issues have included increased price pressures on solar panel components such as polysilicon, pandemic-related port closures, port congestion and ship diversions, and increases in shipping rates from trans-Pacific ocean carriers due to factors that include limited availability of shipping capacity, shortages of shipping containers, shortages of dock workers and truck drivers and increases in fuel prices. These factors have contributed to price increases and price fluctuations in solar energy equipment, and at times have caused delays in supply. Government tariffs on solar energy equipment, including tariffs placed on solar equipment manufactured in China, have also contributed to higher prices on solar equipment. Additionally, Russia’s war against Ukraine caused price and supply pressure on solar energy equipment, as the war has impacted fuel prices and has led to increased demand in European markets for solar energy equipment as consumers and governments in Europe have sought to establish greater energy independence. In 2020, 2021, and 2022, we experienced periods of temporary delay in obtaining supplies. We believe these delays reduced the number of installations in comparison to what we would have been able to install without the delays. In 2023, we did not experience any appreciable delays in supply.

For more information on risks related to our supply chain, see “Risk Factors — Risks Related to Zeo’s Operations — Due to the limited number of suppliers in our industry, the acquisition of any of these suppliers by a competitor or any shortage, delay, price change, imposition of tariffs or duties or other limitation in our ability to obtain components or technologies we use could result in sales and installation delays, cancellations and loss of customers” and “Risk Factors — Risks Related to Zeo’s Operations — Increases in the cost or reduction in supply of solar energy system and energy storage system components due to tariffs or trade restrictions imposed by the U.S. government could have an adverse effect on our business, financial condition and results of operations.”

Seasonality

Historically, our sales volume and installation activity has been highest during late spring and summer. During this time, consumers in many locations see greater energy needs due to operating air conditioning systems and warm-weather appliances such as swimming pool pumps. Our door-to-door sales efforts are also aided during these months by daylight savings time providing increased daylight hours into the evening, and we have more sales personnel, many of whom are college students, working during these months, as described above. We typically have largely or entirely scaled down our internal sales efforts during the fall, winter, and early spring. Snow, cold weather or other inclement weather can also delay our installation of products and services.

Strategy

We plan to increase our market impact and grow our revenue and profits by pursuing the following strategic objectives:

Expand our operations into additional geographic markets.    We plan to continue to expand in new geographic markets, both organically and through strategic M&A, where favorable net metering policies exist, where the percentage of the addressable residential market that already has residential solar energy systems is generally below 7%, and where we do not believe the market is already oversaturated with competitors. We are actively considering additional markets to enter beyond Florida, Texas, Arkansas and Missouri, as we identify markets which we believe may have large addressable markets and significant customer demand for solar energy.

Increase capacity for efficient growth by investing in people and systems.    We have increased the number of solar energy systems we sell and install by growing and training our internal seasonal sales force, and we plan to continue to do so, as well as increasing our number of external dealers. We have also grown and plan to continue growing our installation capacity in markets we serve by hiring and training more skilled technicians and investing in technology. Where we do not yet have installation teams in place, we plan to continue to collaborate with subcontractors to fulfill our installation needs.

Continue to grow our external dealer sales channel.    We plan to increase the number of external dealers working to bring us customers. We believe we will continue to have success in attracting dealers to our business because of our scalable business platform that allows dealers to participate in the residential solar energy sales and installation life cycle with limited investments in personnel and capital.

Expand customer options for buying affordable solar energy.    We plan to expand our roofing business in all markets we enter in the future. Roofing facilitates a faster processing time for our solar installations in cases where the residential customer is in need of a roof replacement prior to installing solar systems. We believe offering customers the option to lease a residential solar energy system installed on their home will increase the number of systems we can sell and install due to the potential savings for some customers that cannot otherwise take full advantage of certain tax incentives. As described above, in December 2022, we launched a program offering customers the option of leasing residential solar energy systems from third parties that we install on the customer’s home.

Strengths

We are profitable.    We have a profitable business model, and over the last four years, we have increased revenue and earned profit.

In adopting the systems and costs of operating as a publicly traded company, we expect to face challenges to our ability to maintain or increase our profitability. However, we believe our strengths position us for accelerating our growth in an efficient manner that will produce profitable results.

Our Sales Model.    Our sales methodology produces a high volume of sales. We believe our internal sales process drives a high volume of sales per sales representative and results in low customer acquisition costs. The success of our sales processes starts with quality, hands-on training for each sales representative. Our self-produced digital learning platform presents our sales representatives with sample customer scenarios and guides them in learning effective communication techniques, as well as how to efficiently carry out administrative steps required for completing sales. Each sales representative’s responses to sample customer scenarios are reviewed and critiqued by managers of our internal sales team.

In our sales model, a majority of personnel knock on doors of potential customers and explain the benefits of solar energy and our offerings with the objective of scheduling a subsequent sales meeting. In the scheduled meetings, a more experienced sales representative or sales manager provides a homeowner additional information about system design, energy savings and other benefits, pricing, incentives and financing options.

We believe that the key elements to our successful business model include (i) effective training and time spent with senior sales managers, (ii) our use of our customer relationship management software platform which concurrently tracks key performance indicators across the sales cycle, and (iii) our multi-step setter-closer sales model, which enables senior sales personnel to focus on greater sales success in presentations, while setters focus on developing and filtering quality, qualified leads, all of which then contributes to maximizing the percentage of leads converted into sales and sales into installations because of satisfied customers throughout the process.

____________

(1)      As of December 31, 2023.

(2)      During the Company’s peak sales period in late Spring and Summer of 2023. See “— Seasonality” above.

Our vertical integration leads to customer satisfaction and personnel retention.    We believe our vertically integrated business model, in which we market, design, sell, procure, install and service systems, has a major benefit of enhancing the speed of project completion after an initial sale is made. It also allows us to price projects strategically with information from both the sales and installation sides of the process. Our greater control over the total process and our resulting success rates in navigating the local municipal permit process is intended to increase customer satisfaction and reduce potential sales force frustration from losing many jobs due to delays in the installation process. Our ratio of sales converted to completed installations is higher for sales that come from our internal agents than that that come from our dealer sales. We believe this higher rate helps increase the job satisfaction and retention rate for our personnel, as it enhances commissions that are paid out to sales personnel and managers, and provides work for installation teams.

Our scalable business platform allows us to grow efficiently.    We believe that we have established a scalable business platform for efficiently completing the life-cycle of tasks involved in offering and fulfilling customers’ residential solar power needs. This platform is principally: (a) software we use in designing, selling, installing and servicing systems, and in tracking key performance indicators across the sales cycle; and (b) the business processes of our employees that perform field work, system design, permitting, installation and back-office support tasks. This platform is intended to allow us to undergo rapid sales and installation growth by efficiently adding new personnel and collaborating effectively with external dealers who bring us additional customers. We have carefully designed these processes and our pre- and post-installation operations to be effective systems which can be easily explained to new employees and replicated in the new cities and regions in which we operate and expand.

Competition

The solar energy and renewable energy industries are both highly competitive and continually evolving as participants strive to distinguish themselves within their markets and compete with large electric utilities.

We consider our primary competitors to be electric utilities that supply electricity to our potential customers. We compete with these electric utilities primarily based on price (cents per kWh), predictability of future prices and the ease by which customers can switch to electricity generated by our residential solar energy systems. We may also compete with them based on other value-added benefits. These include reliability and carbon-friendly power, benefits which consumers have historically paid a premium to secure, but which customers can obtain by purchasing a solar energy system for monthly costs that are sometimes equal to or less than a traditional monthly power bill from the utility.

We also compete with retail electric providers and independent power producers that are not regulated like electric utilities but which have access to the utilities’ electricity transmission and distribution infrastructure pursuant to state, territorial and local pro-competition and consumer choice policies. These retail electric providers and independent power producers can offer customers electricity solutions that are competitive with our residential solar energy system options on both price and usage of renewable energy technology while avoiding the physical installations that our current business model requires.

We compete with community solar products offered by solar companies or sponsored by local governments and municipal power companies, as well as utility companies that provide renewable power purchase programs. Some customers might choose to subscribe to a community solar project or renewable subscriber program instead of having a residential solar energy system installed on their home, which could affect our sales. Additionally, some utility companies (and some utility-like entities, such as community choice aggregators) have power generation portfolios that are increasingly renewable in nature. As utility companies offer increasingly renewable portfolios to retail customers, those customers might be less inclined to have a residential solar energy system installed on their home or business, which could adversely affect our growth.

We also compete with solar energy companies with vertically integrated business models like our own, many of which are larger than we are. For example, some of our competitors offer their own consumer financing products to customers and/or produce one or more components of the residential solar energy system or energy storage system. In addition to financing and manufacturing, some other business models also include sales, engineering, installation, maintenance and monitoring services. Some of our competitors also have an established complementary construction, electrical contracting or roofing services.

Some competitors also offer customers the option of leasing a residential solar energy system installed on the customer’s residence. In such a scenario, the provider or a third party owns the residential solar energy system, and the customer typically pays a predetermined fee for the electricity produced by the residential solar energy system. The fee generally increases annually at a predetermined rate over the lease term, which is typically 20 to 25 years, with a renewal option. Such a lease program can take fuller advantage of some of the available tax incentives and, therefore, can reduce the customer’s monthly costs in comparison to owning the residential solar energy system.

We compete against companies that are not vertically integrated, such as companies that offer only installation services, or provide only equipment to be installed, or dealers that sell systems for which another entity or entities will provide and install equipment. Some of these entities finance products directly to consumers, inclusive of programs like Property-Assessed Clean Energy financing programs established by local governments. For example, we face competition from solar installation businesses that seek financing from external parties or utilize competitive loan products or state and local programs.

We expect the competition to evolve as the market continues to grow, evolve and attract new market entrants. We believe that with our business model and sales strategy, we can compete effectively and favorably within the industry.

For more information on risks relating to increased competition in our industry, see “Risk Factors — Risks Related to the Solar Industry — We face competition from electric utilities, retail electric providers, independent power producers, renewable energy companies and other market participants.”

Intellectual Property

We protect our intellectual property rights by relying on common law protections and through contractual arrangements. We typically require our personnel, consultants and third parties such as our suppliers with access to our proprietary information to execute confidentiality agreements. Our principal trade secrets and copyrighted materials consist of our sales methodologies and data regarding our personnel, customers and suppliers.

We also license third-party software and services that we use in operating our business. These third-party solutions include, among others, software that we use in selling and designing our products services, a customer relationship management system to actively track key performance indicators across the sales cycle and software to augment our sales and marketing efforts.

Insurance

We maintain the types and amounts of insurance coverage and on terms deemed adequate by management based on our actual claims experience and expectations for future claims. However, future claims could exceed our applicable insurance coverage. Our insurance policies cover employee-and contractor-related accidents and injuries, property damage, business interruption, storm damage, inventory, vehicles, fixed assets, facilities, and crime and general liability deriving from our activities. We have also obtained insurance policies covering directors, officers, employment practices, auto liability, and commercial general liability. We may also be covered in some circumstances for certain liabilities by insurance policies owned by third parties, including, but not limited to, our dealers and vendors.

Government Regulation

U.S. tariffs, duties and other trade regulations impact the prices of components in the residential solar energy systems and energy storage systems we sell, in addition to the pricing pressures caused by supply chain factors as discussed above. These U.S. government-based pricing influences currently include tariffs placed on crystalline silicon PV cells and solar panels imported into the U.S. Also, China is a major producer of solar modules, inverters and other components that we use in the systems that we install, and the U.S. currently assesses various tariffs and antidumping and countervailing duties on equipment produced in China, including solar modules and inverters. The U.S. has also placed certain geographic, company-specific and other trade restrictions on Chinese sources of supply based on foreign policy and national security interests. The scope and timing of these regulatory efforts change over time, and the government may introduce new regulations as world events occur and public policy evolves. In response to the market uncertainty and price fluctuations caused by these government actions and other supply chain pressures, we carefully and periodically evaluate our suppliers of system components and make purchasing decisions based on our judgments of product quality, warranties, pricing and availability.

For more information on risks relating to government tariffs, duties or trade restrictions, see “Risk Factors — Risks Related to Zeo’s Operations — Increases in the cost or reduction in supply of residential solar energy system and energy storage system components due to tariffs or trade restrictions imposed by the U.S. government could have an adverse effect on our business, financial condition and results of operations.”

Our operations are subject to various national, state and local laws and regulations. These include regulations regarding license requirements for electricians or other professionals involved in the installation of residential solar energy systems and energy storage systems. Many states and/or local governments and utilities have regulated procedures for interconnecting residential solar energy systems and related energy storage systems to the utility’s local distribution system. There are also local building codes or other local regulations for installing the products we sell on a customer’s property. We employ or contract with licensed professionals as needed to comply with regulatory requirements, and as part of our process of installing residential solar energy systems and related equipment, we assist our customers in obtaining interconnection permission from the applicable local electric distribution utility, and applicable permits from other local offices.

Our operations, as well as those of our suppliers and subcontractors, are subject to stringent and complex U.S. federal, state, territorial and local laws, including regulations governing the occupational health and safety of employees, wage regulations and environmental protection. For example, we and our suppliers and subcontractors are subject to the regulations OSHA, the U.S. Department of Transportation (“DOT”), the U.S. Environmental Protection Agency

(“EPA”) and comparable state entities that protect and regulate employee health and safety and the protection of the environment. Various environmental, health and safety laws can result in the imposition of costs and liability in connection with system and equipment installation, the repair or replacement of parts, and disposal of hazardous substances (such as the disposal and recycling of batteries).

We and the dealers that supply us with sales opportunities or completed sales are also subject to laws and regulations related to interactions with consumers, including those applicable to sales and trade practices, privacy and data security, equal protection, consumer financial and credit transactions, consumer collections, mortgages and re-financings, home or business improvements, trade and professional licensing, warranties, and various means of customer solicitation, as well as specific regulations pertaining to solar installations.

Government Incentives

There are U.S. federal, state and local governmental bodies that provide incentives to owners, distributors, installers and manufacturers of residential solar energy systems to promote solar energy. These incentives include an investment tax credit and income tax credit offered by the federal government, as well as other tax credits, rebates and Solar Renewable Energy Credits associated with solar energy generation. The U.S. federal Energy Policy Act of 2005, as amended, established what came to be known as the Residential Energy Efficient Property Credit, an incentive that provides homeowners a 30% tax credit for the cost of purchasing and installing qualified residential alternative energy equipment, including solar electricity equipment. The IRA renamed this credit as the Residential Clean Energy Credit and extended the 30% credit through 2032. The credit rate falls to 26% in 2033, 22% for 2034 and expires at the end of 2034. The IRA also provides other incentives for homeowners to adopt energy-efficient systems and appliances that include: (a) a 30% tax credit with an annual limit for certain upgrades such as installing energy-efficient hybrid water heaters, doors and windows, insulation, and upgrading electrical breaker boxes; and (b) up to $14,000 in point-of-sale rebates for low- and moderate-income households for certain electric appliances and home upgrades.

Our business model also relies on multiple tax exemptions offered at the state and local levels. For example, some states have property tax exemptions that exempt the value of residential solar energy systems in determining values for calculation of local and state real and personal property taxes, and there are some state and local tax exemptions that apply to the sale of equipment. State and local tax exemptions can have sunset dates or triggers for loss of the exemption, and the exemptions can be changed by state legislatures and other regulators.

A majority of states have adopted net metering policies, including our sales areas of Florida, Texas, Arkansas and Missouri. Net metering policies allow homeowners to serve their own energy load using on-site generation while avoiding the full retail volumetric charge for electricity. Electricity that is generated by a residential solar energy system and consumed on-site avoids a retail energy purchase from the applicable utility, and excess electricity that is exported back to the electric grid generates a retail credit within a homeowner’s monthly billing period. At the end of the monthly billing period, if the homeowner has generated excess electricity within that month, the homeowner typically carries forward a credit for any excess electricity to be offset against future utility energy purchases. At the end of an annual billing period or calendar year, utilities either continue to carry forward a credit or reconcile the homeowner’s final annual or calendar year bill using different rates (including zero credit) for the exported electricity.

Utilities, their trade associations, and other entities are currently challenging net metering policies in various locations by seeking to eliminate them, cap them, reduce the value of the credit provided to homeowners for excess generation or impose charges on homeowners that have net metering. States where we sell now or in the future may change, eliminate or reduce net metering benefits. On April 26, 2022, the Florida governor vetoed legislation that would have established a date for reducing and ending net metering in Florida.

We rely on a mix of the incentives mentioned above to reduce the net price our customers that are eligible for incentives would otherwise pay for our solar offerings or per kilowatt hour used.

Employees and Human Capital Management

As of December 31, 2023, we have approximately 190 full-time employees that work year-round processing orders, installing and servicing systems and fulfilling administrative tasks. We also engage sales agents as independent contractors as described in “— Internal Direct Sales Force” above. None of our employees are covered by collective bargaining agreements, and we have not experienced any work stoppages due to labor disputes.

Facilities

Our corporate headquarters are located in Florida under a lease that expires at the end of October 2026. We maintain offices for operations in Texas and Arkansas, and we have sales, marketing and executive offices in Utah and throughout Florida. We currently lease the office and warehouse spaces that we use in our operations, and we do not own any real property. We believe that our facility space adequately meets our needs and that we will be able to obtain any additional operating space that may be required on commercially reasonable terms.

Litigation

We are not currently a party to any material litigation or governmental or other proceeding. However, from time to time, we have been, are and will likely continue to be involved in legal proceedings, administrative proceedings and claims that arise in the ordinary course of business with customers, subcontractors, suppliers, regulatory bodies or others. In general, litigation claims or regulatory proceedings can be expensive and time consuming to bring or defend against, which may result in the diversion of management’s attention and resources from our business and business goals and could result in settlement or damages that could significantly affect financial results and the conduct of our business.

MANAGEMENT’S DISCUSSION AND ANALYSIS OF FINANCIAL CONDITION
AND RESULTS OF OPERATIONS

The following discussion and analysis should be read in conjunction with Sunergy’s financial statements and related notes included elsewhere in this prospectus. This discussion and analysis should also be read in conjunction with Unaudited Pro Forma Condensed Combined Financial Information. In addition to historical information, this discussion and analysis includes certain forward-looking statements which reflect our current expectations. Our actual results may materially differ from these forward-looking statements as a result of many factors. Please see “Cautionary Statement Regarding Forward-Looking Statements” and “Risk Factors” in this prospectus.

Overview

Our mission is to expedite the country’s transition to renewable energy by offering our customers an affordable and sustainable means of achieving energy independence. We are a vertically integrated provider of residential solar energy systems, other energy efficient equipment and related services currently serving customers in Florida, Texas, Arkansas and Missouri. Sunergy was created on October 1, 2021 through the contribution of Sun First Energy, LLC, a rapidly growing solar sales management company, and Sunergy Solar LLC, a large solar installation company based in Florida, to Sunergy Renewables, LLC.

We believe that we have built (and continue to build) the infrastructure and capabilities necessary to rapidly acquire and serve customers in a low-cost and scalable manner. Today, our scalable regional operating platform provides us with a number of advantages, including the marketing of our solar service offerings through multiple channels, including our diverse sales partner network and direct-to-consumer vertically integrated sales and installation operations. We believe that this multi-channel model supports rapid sales and installation growth, allowing us to achieve capital-efficient growth in the regional markets we serve.

Since our founding, we have continued to invest in a platform of services and tools to enable large scale operations for us and our partner network, which includes sales partners, installation partners and other strategic partners. The platform includes processes and software, as well as fulfillment and acquisition of marketing leads. We believe our platform empowers our in-house sales team and external sales dealers to profitably serve our regional and underpenetrated markets and helps us compete effectively against larger, more established industry players without making significant investment in technology and infrastructure.

We have focused to date on a simple, capital light business strategy utilizing, as of December 31, 2023, approximately 270 sales agents and approximately 30 independent sales dealers to produce a growing sales pipeline. We engineer and design projects and process building permit applications on behalf of our customers to timely install their systems and assist their connection to the local utility power grid. Most of the equipment we install is drop-shipped to the installation site by our regional distributors, requiring minimal inventory to be held by the Company during any given period. We depend on our distributors to timely handle logistics and related requirements in moving equipment to the installation sites. In addition to our main offering of residential solar energy systems, we sell and install products such as roofing, insulation, energy efficient appliances and battery storage systems for the residential market.

We believe that continued government policy support of solar and increasing conventional utility costs provide the solar energy market with material headwinds for accelerating adoption in the United States, which currently lags other international markets, including Australia and Europe. We offer our products and services throughout Florida, Texas, Arkansas and Missouri and plan to enter new markets selectively where favorable net metering policies exist and solar penetration is below 7% of the addressable residential market. Most of our sales were generated in Florida through December 31, 2023 and 2022 with the remainder for each period generated in Texas, Arkansas, and Missouri. We have focused on improving our operational efficiency to meet the growing demand for our services and have increased our installation capacity by investing in new equipment and technology. We have also expanded our workforce by hiring more skilled technicians and training them extensively to ensure that they meet our high standards for quality and safety.

Our core solar service offerings are generated by customer purchases and financing through third-party long-term lenders that provide customers with simple, predictable pricing for solar energy that is insulated from rising retail electricity prices. Most of our customers finance their purchases with affordable loans from third-party lenders that require minimal or no upfront capital or down payment. We have also launched a leasing program where a third-party

purchases the residential solar energy system that we install on the customer’s property. Our Chief Executive Officer is also the Chief Executive Officer and minority owner of the third-party that provides the lease financing to the customer. For these transactions, the Company’s performance obligation remains the same as if the transaction was financed with a third-party lender. We believe this leasing option may better suit some homeowners in a higher interest rate environment who may not have a need for the investment tax credits associated with investing in renewable energy.

Business Combination

On the Closing Date, we consummated the Business Combination. Prior to the Closing, (i) except as otherwise specified in the Business Combination Agreement, each issued and outstanding ESGEN Class B ordinary share was converted into one ESGEN Class A ordinary share; and (ii) ESGEN was domesticated into the State of Delaware so as to become a Delaware corporation. In connection with the Closing, we changed our name from “ESGEN Acquisition Corporation” to “Zeo Energy Corp.”

Following the Domestication, each then-outstanding ESGEN Class A ordinary share was converted into one share of Class A Common Stock, and each then-outstanding ESGEN Public Warrant converted automatically into a Warrant, exercisable for one share of Class A Common Stock. Additionally, each outstanding unit of ESGEN was cancelled and separated into one share of Class A Common Stock and one-half of one Warrant.

In accordance with the terms of the Business Combination Agreement, Sunergy caused all holders of any options, warrants or rights to subscribe for or purchase any equity interests of Sunergy or its subsidiaries or securities (including debt securities) convertible into or exchangeable for, or that otherwise conferred on the holder any right to acquire, any equity interests of Sunergy or any subsidiary thereof (collectively, the “Sunergy Convertible Interests”) existing immediately prior to the Closing to either exchange or convert all such holder’s Sunergy Convertible Interests into limited liability interests of Sunergy (the “Sunergy Company Interests”) in accordance with the governing documents of Sunergy or the Sunergy Convertible Interests.

At the Closing, ESGEN contributed to OpCo (1) all of its assets (excluding its interests in OpCo, but including the amount of cash in ESGEN’s Trust Account as of immediately prior to the Closing (after giving effect to the exercise of redemption rights by ESGEN shareholders)), and (2) a number of newly issued shares of Class V Common Stock, which are non-economic, voting shares of Zeo, equal to the number of Seller OpCo Units (as defined in the Business Combination Agreement) and (y) in exchange, OpCo issued to ESGEN (i) a number of Class A common units of OpCo (the “OpCo Manager Units”) which equaled the total number of shares of Class A Common Stock issued and outstanding immediately after the Closing and (ii) a number of warrants to purchase OpCo Manager Units which equaled the number of Warrants issued and outstanding immediately after the Closing (the transactions described above in this paragraph, the “ESGEN Contribution”). Immediately following the ESGEN Contribution, (x) the Sellers contributed to OpCo the Sunergy Company Interests and (y) in exchange therefor, OpCo transferred to the Sellers the Seller OpCo Units and the Seller Class V Shares.

Prior to the Closing, Sellers transferred 24.167% of their Sunergy Company Interests (which were thereafter exchanged for Seller OpCo Units and Seller Class V Shares at the Closing, as described above) pro rata to Sun Managers, LLC, a Delaware limited liability company (“Sun Managers”), in exchange for Class A Units (as defined in the Sun Managers limited liability company agreement (the “SM LLCA”)) in Sun Managers. In connection with such transfer, Sun Managers executed a joinder to, and became a “Seller” for purposes of, the Business Combination Agreement. Sun Managers intends to grant Class B Units (as defined in the SM LLCA) in Sun Managers through the Sun Managers, LLC Management Incentive Plan (the “Management Incentive Plan”) adopted by Sun Managers to certain eligible employees or service providers of OpCo, Sunergy or their subsidiaries, in the discretion of Timothy Bridgewater, as manager of Sun Managers. Such Class B Units may be subject to a vesting schedule, and once such Class B Units become vested, there may be an exchange opportunity through which the grantees may request (subject to the terms of the Management Incentive Plan and the OpCo A&R LLC Agreement) the exchange of their Class B Units into Seller OpCo Units (together with an equal number of Seller Class V Shares), which may then be converted into Class A Common Stock (subject to the terms of the Management Incentive Plan and the OpCo A&R LLC Agreement). Grants under the Management Incentive Plan will be made after Closing.

As of the Closing Date, upon consummation of the Business Combination, the only outstanding shares of capital stock of the registrant were shares of Class A Common Stock and Class V Common Stock.

In connection with entering into the Business Combination Agreement, ESGEN and the Sponsor entered into the Sponsor Subscription Agreement, pursuant to which, among other things, the Sponsor agreed to purchase an aggregate of 1,000,000 Convertible OpCo Preferred Units convertible into Exchangeable OpCo Units (and be issued an equal number of shares of Class V Common Stock) concurrently with the Closing at a cash purchase price of $10.00 per unit and up to an additional 500,000 Convertible OpCo Preferred Units (together with the concurrent issuance of an equal number of shares of Class V Common Stock) during the six months after Closing if called for by Zeo. Prior to the Closing, ESGEN informed the Sponsor that it wished to call for the additional 500,000 Convertible OpCo Preferred Units at the Closing and, as a result, a total of 1,500,000 Convertible OpCo Preferred Units and an equal number of shares of Class V Common Stock were issued to Sponsor pursuant to the Sponsor Subscription Agreement for aggregate consideration of $15,000,000.

Accounting for the Business Combination

Following the Business Combination, we are organized in an “Up-C” structure, such that Sunergy and the subsidiaries of Sunergy hold and operate substantially all of the assets and businesses of the registrant, and the registrant is a publicly listed holding company that holds a certain amount of equity interests in OpCo, which holds all of the equity interests in Sunergy. The Class A Common Stock and public warrants are traded on Nasdaq under the ticker symbols “ZEO” and “ZEOWW,” respectively.

The Business Combination was accounted for as a reverse recapitalization with ESGEN being treated as the acquired company since there was no change in control in accordance with the guidance for common control transactions in ASC 805-50. Accordingly, the financial statements of the combined entity will represent a continuation of the financial statements of Sunergy with the business combination treated as the equivalent of Sunergy issuing stock for the net assets of ESGEN, accompanied by a recapitalization. The net assets of ESGEN were stated at historical cost, with no goodwill or other intangible assets recorded. Operations prior to the Business Combination were those of Sunergy.

Sunergy was determined to be the accounting acquirer based on evaluation of the following facts and circumstances:

Based upon the evaluation of the OpCo A&R LLC Agreement, the Sellers contributed their interests of Sunergy into OpCo. OpCo’s members did not have substantive kickout or participating rights and therefore OpCo is a VIE. Consideration of OpCo as a VIE was necessary to determine the accounting treatment between ESGEN and Sunergy. Upon evaluation, ESGEN was considered to be the primary beneficiary through its membership interest and manager powers conferred to it through the Class A Units. For VIEs, the accounting acquirer is always considered to be the primary beneficiary. As such, ESGEN will consolidate OpCo and is considered to the accounting acquirer; however, further consideration of whether the entities are under common control was required in order to determine whether there is an ultimate change in control and the acquisition method of accounting is required under ASC 805.

While Sunergy did not control or have common ownership of ESGEN prior to the consummation of the Business Combination, the Company evaluated the ownership of the new entity subsequent to the consummation of the transaction to determine if a change in control occurred by evaluating whether Sunergy was under common control prior to and subsequent to the consummation of the transaction. If the business combination is between entities under common control, then the acquisition method of accounting is not applicable and the guidance in ASC 805-50 regarding common control should be applied instead. EITF Issue 02-5 “Definition of ‘Common Control’ in Relation to FASB Statement No. 141” indicates that common control would exist if a group of shareholders holds more than 50 percent of the voting ownership of each entity, and contemporaneous written evidence of an agreement to vote a majority of the entities’ shares in concert exists. Prior to the Business Combination, Sunergy was majority owned by five entities (the “Primary Sellers”), who entered into a Voting Agreement, dated September 7, 2023. The term of the Voting Agreement is for five years from the date of the Voting Agreement. The consummation of the Business Combination with ESGEN occurred within the term of the Voting Agreement.

Prior to the Business Combination and the contributions to Sun Managers as described above, the Primary Sellers had 98% ownership in Sunergy. Immediately following the Business Combination, the Sellers now own 83.8% of the equity of the Company.

The Voting Agreement constitutes contemporaneous written evidence of an agreement to vote a majority of the Primary Sellers’ shares of the Company in concert. Accordingly, the Primary Sellers retain majority control through the voting of their units in conjunction with the Voting Agreement immediately prior to the Business Combination and their shares following the Business Combination and, therefore, there was no change of control before or after the

Business Combination. This conclusion was appropriate even though there was no relationship or common ownership or control between Sunergy and ESGEN prior to the Business Combination. Accordingly, the Business Combination should be accounted for in accordance with the guidance for common control transactions in ASC 805-50.

Additional factors that were considered include the following:

•        Since the Business Combination, the Board has been comprised of one individual designated by ESGEN and five individuals designated by Sunergy.

•        Since the Business Combination, management of the Company has been the existing management at Sunergy immediately prior to the Business Combination. The individual that was serving as the chief executive officer and chief financial officer of Sunergy’s management team immediately prior to the Business Combination continues substantially unchanged upon completion of the Business Combination.

For common control transactions that include the transfer of a business, the reporting entity is required to account for the transaction in accordance with the procedural guidance in ASC 805-50. In essence, the Business Combination will be treated as a reverse recapitalization with ESGEN being treated as the acquired company since there was no change in control. Accordingly, the financial statements of the combined entity will represent a continuation of the financial statements of Sunergy with the business combination treated as the equivalent of Sunergy issuing equity for the net assets of ESGEN, accompanied by a recapitalization.

Public Company Costs

Following the Business Combination, we have ongoing reporting and other compliance requirements relating to our Exchange Act registration and Nasdaq listing. We expect to see an increase in general and administrative costs, compared to historic results, to support the legal and accounting requirements of the combined publicly traded company. We also expect to incur substantial additional expenses for, among other things, directors’ and officers’ liability insurance, director fees, internal control compliance, and additional costs for investor relations, accounting, audit, legal and other functions.

Key Operating and Financial Metrics and Outlook

We regularly review a number of metrics, including the following key operating and financial metrics, to evaluate our business, measure our performance, identify trends in our business, prepare financial projections and make strategic decisions. We believe the operating and financial metrics presented below are useful in evaluating our operating performance, as they are similar to measures by our public competitors and are regularly used by security analysts, institutional investors and other interested parties in analyzing operating performance and prospects. Adjusted EBITDA and Adjusted EBITDA margin are non-GAAP measures, as they are not financial measures calculated in accordance with GAAP and should not be considered as substitutes for net (loss) income or net (loss) income margin, respectively, calculated in accordance with GAAP. See “— Non-GAAP Financial Measures” for additional information on non-GAAP financial measures and a reconciliation of these non-GAAP measures to the most comparable GAAP measures.

The following table sets forth these metrics for the periods presented:

Adjusted EBITDA and Adjusted EBITDA Margin

We define Adjusted EBITDA, a non-GAAP financial measure, as net income (loss) before interest expense, PPP loan forgiveness, other expenses, net, income tax expense, depreciation and amortization, as adjusted to exclude merger and acquisition expenses (“M&A expenses”). We define Adjusted EBITDA margin, a non-GAAP financial measure, expressed as a percentage, as the ratio of Adjusted EBITDA to revenue, net. See “— Non-GAAP Financial Measures” for a reconciliation of GAAP net loss to Adjusted EBITDA and a ratio of GAAP net loss to revenue, net.

Key Factors that May Influence Future Results of Operations

Our financial results of operations may not be comparable from period to period due to several factors. Key factors affecting the results of our operations are summarized below.

Expansion of Residential Sales into New Markets.    Our future revenue growth is, in part, dependent on our ability to expand our product offerings and services in the select residential markets where we operate in Florida, Texas, Arkansas and Missouri. We primarily generate revenue from our sales, product offerings and services in the residential housing market. To continue our growth, we intend to expand our presence in the residential market into additional states based on markets underserved by national sales and installation providers that also have favorable incentives and net metering policies. We believe that our entry into new markets will continue to facilitate revenue growth and customer diversification.

Expansion of New Products and Services.    In fiscal year 2023 we sold over $6.8 million in roofing replacements to facilitate our solar installations and to repair rooftops on homes in Florida damaged by severe weather. We plan to expand our roofing business in all markets we enter in the future. Roofing facilitates a faster processing time for our solar installations in cases where the customer is in need of a roof replacement prior to installing a solar system. In addition, to provide more financing options for our prospective residential solar energy customers, in fiscal year 2023, we launched a program that allows customers to choose a leasing option to finance their systems from a third party. We expect selling systems utilizing third party leases under this and other similar programs to be a growing portion of our customer finance offerings in the future.

Adding New Customers and Expansion of Sales with Existing Customers.    We intend to approximately double our in-house sales force and external sales dealers in 2024 in order to target new customers in the Southern U.S. regional residential markets. We provide competitive compensation packages to our in-house sales teams and external sales dealers, which incentivizes the acquisition of new customers.

Inflation.    We are seeing an increase in the costs of labor and components as the result of higher inflation rates. In particular, we are experiencing an increase in raw material costs and supply chain constraints, and trade tariffs imposed on certain products from China, which may continue to put pressure on our operating margins and increase our costs. We do not have information that allows us to quantify the specific amount of cost increases attributable to inflationary pressures.

Interest rates.    Interest rate increases for both short-term and long-term debt have increased sharply. Historically, most of our customers have financed the purchase of their solar systems. Higher interest rates have resulted in higher monthly costs to customers, which has the effect of slowing the financing related sales of solar systems in the areas in which we sell and operate. We do not have information that allows us to quantify the adverse affects attributable to increased interest rates.

Managing our Supply Chain.    We rely on contract manufacturers and suppliers to produce our components. We have seen supply chain challenges and logistics constraints increase, including component shortages, which have, in certain cases, caused delays in the delivery of critical components and inventory, created longer lead times, and resulted in increased costs on jobs that were impacted by these issues. We experienced material shortages and an increase in pricing for in 2022 and the beginning of 2023. In the second half of 2023 we have seen a correction in the supply chain. Our suppliers are generally meeting our materials needs and we are realizing a decrease in pricing for our solar components. Our ability to grow depends, in part, on the ability of our contract manufacturers and suppliers to provide high quality services and deliver components and finished products on time and at reasonable costs. In the event we are unable to mitigate the impact of delays and/or price increases in raw materials, electronic components and freight, it could delay the manufacturing and installation of our systems, which would adversely impact our cash flows and results of operations, including revenue and gross margin.

Components of Consolidated Statements of Operations

Revenue, net

Our primary source of revenue is the sale of our residential solar systems. Our systems are made fully functional at the time of installation and require an inspection prior to interconnection to the utility power grid. We sell our systems primarily direct to end user customers for use in their residences. Upon installation inspection, we satisfy our performance obligation and recognize revenue. Many of the Company’s customers finance their obligations with third parties. In these situations, the finance company deducts their financing fees and remits the net amount to the Company. Revenue is recorded net of these financing fees (and/or dealer fees). The volume of sales and installations of rooftop solar systems, our primary product, increase from April to September when a majority of our sales teams are most active in our areas of service. In addition to sales of solar systems, “adders” or accessories to a sale may include roofing, energy efficient appliances, upgraded insulation and/or energy storage systems. All adders consisted of less than 10% of the total revenue, net in each of the years ended December 31, 2023 and 2022.

Our revenue is affected by changes in the volume and average selling prices of our solutions and related accessories, supply and demand, sales incentives and fluctuating interest rates. Approximately 95% of our sales were financed by the customer in each of the years ended December 31, 2023 and 2022. Our revenue growth is dependent on our ability to compete effectively in the marketplace by remaining cost competitive, developing and introducing new sales teams within existing and new territories, scaling our installation teams to keep up with demand and maintaining a strong internal operations team to process orders while working with building departments and utilities to permit and interconnect our customers to the utility grid.

Cost of Goods Sold

Our cost of goods sold consists primarily of product costs (including solar panels, inverters, metal racking, connectors, shingles, wiring, warranty costs and logistics costs), sales commissions, installation labor and permitting costs.

During 2023 and 2022, supply chain challenges and an increase in demand for our products resulted in increased equipment costs and delays. As a result, our installation and sales growth was less than we had projected. Additionally, in October 2022 our primary market in Florida was hit with Hurricane Ian, which also slowed permitting and installations of our systems in Florida and required some crews to divert to repairing roofs and damaged solar systems.

Revenue, net less cost of goods sold may vary from period-to-period and is primarily affected by our average selling prices, finance dealer fees, fluctuations in equipment costs and our ability to effectively and timely deploy our field installation teams to project sites once the permitting departments have approved the design and engineering of systems on customer sites.

Operating Expenses

Operating expenses consist of sales and marketing and general and administrative expenses. Personnel-related costs are the most significant component of each of these expense categories and include salaries, benefits and payroll taxes. In the future, the Company intends to provide more benefits to its employees, including an employee stock plan, which will increase operating expenses.

Sales and marketing expenses consist primarily of personnel-related expenses, as well as advertising, travel, trade shows, marketing, customer support and other indirect costs. We expect to continue to make the necessary investments to enable us to execute our strategy to increase our market penetration geographically and enter into new markets by expanding our base sales teams, installers and strategic sales dealer and partner network.

General and administrative expenses consist primarily of personnel-related expenses for our executive, finance, human resources, information technology, and software, facilities costs and fees for professional services. Fees for professional services consist primarily of outside legal, accounting and information technology consulting costs.

Depreciation and amortization consist primarily of deprecation of our vehicles, furniture and fixtures, internally developed software and amortization of our acquired intangibles.

Interest and Other Expenses, Net

Interest and other expenses, net primarily consist of interest expense and fees under our equipment and vehicle term loans. Other expense, net also includes interest income on our cash balances, and accrued interest on tariffs previously paid and approved for refund.

Results of Operations

Year Ended December 31, 2023 Compared to Year Ended December 31, 2022

The following table sets forth a summary of our consolidated statements of operations for the periods presented:

Revenue, net

Revenue, net increased by approximately $21.1 million as a result of increases in sales volume from our internal sales teams and decreases in sales volume from sales by our dealer network.

Cost of Goods Sold

Cost of goods sold increased $16.8 million as a result of the increase in revenues as noted above. As a percentage of revenue, the cost of goods sold was 80.0% for the year ended December 31, 2023 which was consistent with the year ended December 31, 2022.

Depreciation and amortization

The $0.2 million increase was a result of the increase in our vehicle fleet in 2023 and the associated depreciation of the new vehicles.

General and Administrative expenses

The $6.5 million increase is primarily due to an increase in headcount and infrastructure related expenses to support the increase in revenues in the year and expenses related to the business combination.

Sales and Marketing

The $0.2 million decrease was a result of efforts to focus on sales and marketing spending in our most efficient areas. Therefore, we were able to increase sales in the year without increasing the sales and marketing expenses.

Other expense, net

The $0.2 million increase was due primarily to the loss on the disposition of assets of $103,000 in 2023 and the realization of $74,000 of income from the forgiveness of a PPP loan in 2022.

Liquidity and Capital Resources

Our primary source of funding to support operations have historically been from cash flows from operations. Our primary short-term requirements for liquidity and capital are to fund general working capital and capital expenses. Our principal long-term working capital uses include ensuring revenue growth, expanding our sales and marketing efforts and potential acquisitions.

As of December 31, 2023 and 2022, our approximate cash and cash equivalents balance was $8.0 million and $2.3 million, respectively. The Company maintains its cash in checking and savings accounts.

Our future capital requirements depend on many factors, including our revenue growth rate, the timing and extent of our spending to support further sales and marketing, the degree to which we are successful in launching new business initiatives and the cost associated with these initiatives, and the growth of our business generally.

In order to finance these opportunities and associated costs, it is possible that we will need to raise additional capital through either debt or equity financing if the proceeds realized from the Business Combination are insufficient to support our business needs.

While we believe that the proceeds realized through the Business Combination will be sufficient to meet our currently contemplated business needs for the next twelve months, we cannot assure you that this will be the case. If additional financing is required by us from outside sources, we may not be able to raise it on terms acceptable to us or at all. If we are unable to raise additional capital on acceptable terms when needed, our business, results of operations and financial condition would be materially and adversely affected.

Cash Flows

The following table summarizes our cash flows for the periods presented:

Cash flows from operating activities

Net cash provided by operating activities was approximately $12.0 million during 2023 compared to approximately $10.7 million during 2022. The increase in net cash provided by operating activities was primarily due to an increase in net income excluding depreciation and amortization of approximately $0.9 million as well as an increase in our contract liabilities of approximately $3.9 million offset by an increase in accounts receivable of $4.1 million and an increase in prepaid installation costs of $6.2 million.

Cash flows from investing activities

Net cash used in investing activities was approximately $1.8 million for the year ended December 31, 2023 primarily relating to purchases of property and equipment, primarily vehicles. Net cash provided by investing activities for the year ended December 31, 2022 was approximately $1.1 million primarily relating to purchases of vehicles.

Cash flows used in financing activities

For the year ended December 31, 2023, net cash used in financing activities was approximately $4.4 million, which primarily represented the distribution to members, which was offset by issuance of debt less repayments. This compares to net cash used in financing activities for the year ended December 31, 2022 of approximately $7.8 million, which primarily represented the distributions to members, which was offset by issuance costs.